Form 8-K - Current report

UNITED STATES
SECURITIES AND EXCHANGE COMMISSION
WASHINGTON, D.C. 20549

FORM 8-K

CURRENT REPORT

Pursuant to Section 13 or 15(d) of the Securities Exchange Act of 1934

    Date of Report (Date of earliest event reported): September 16, 2024

   

CleanSpark, Inc.

(Exact name of Registrant as Specified in Its Charter)


Nevada	001-39187	87-0449945
(State or Other Jurisdiction of Incorporation)	(Commission File Number)	(IRS Employer Identification No.)

10624 S. Eastern Ave. Suite A - 638
Henderson, Nevada		89052
(Address of Principal Executive Offices)		(Zip Code)

    Registrant’s Telephone Number, Including Area Code: (702) 989-7692

   

(Former Name or Former Address, if Changed Since Last Report)

Check the appropriate box below if the Form 8-K filing is intended to simultaneously satisfy the filing obligation of the registrant under any of the following provisions:

☐Written communications pursuant to Rule 425 under the Securities Act (17 CFR 230.425)

☐Soliciting material pursuant to Rule 14a-12 under the Exchange Act (17 CFR 240.14a-12)

☐Pre-commencement communications pursuant to Rule 14d-2(b) under the Exchange Act (17 CFR 240.14d-2(b))

☐Pre-commencement communications pursuant to Rule 13e-4(c) under the Exchange Act (17 CFR 240.13e-4(c))

Securities registered pursuant to Section 12(b) of the Act:


Title of each class	Trading Symbol(s)	Name of each exchange on which registered
Common Stock, par value $0.001 per share	CLSK	The Nasdaq Stock Market LLC

Indicate by check mark whether the registrant is an emerging growth company as defined in Rule 405 of the Securities Act of 1933 (§ 230.405 of this chapter) or Rule 12b-2 of the Securities Exchange Act of 1934 (§ 240.12b-2 of this chapter).

Emerging growth company ☐

If an emerging growth company, indicate by check mark if the registrant has elected not to use the extended transition period for complying with any new or revised financial accounting standards provided pursuant to Section 13(a) of the Exchange Act. ☐

Item 1.01 Entry into a Material Definitive Agreement.

Clinton, MS Acquisitions

On September 16, 2024, CSRE Properties Mississippi, LLC (the "Buyer"), a wholly-owned subsidiary of CleanSpark, Inc., a Nevada corporation (the "Company"), entered into definitive agreements to acquire 16.5 megawatts of bitcoin mining facilities in Clinton, Mississippi for a total purchase price of up to $5,775,000.

The Buyer entered into a Membership Interest Purchase Agreement (the "MIPA") with Eyas Investment Group Limited, a British Virgin Islands business company (the "MIPA Seller"), pursuant to which the Buyer purchased one hundred percent (100%) of the membership interests of Clinton16.5, LLC, a Mississippi limited liability company, from the MIPA Seller. The Buyer also entered into a Real Estate Purchase and Sale Agreement (the “PSA” and, together with the MIPA, the "Agreements") with Makerstar Capital, Inc., a Delaware corporation (the “PSA Seller” and, together with the MIPA Seller, the "Sellers"), pursuant to which the Buyer agreed to purchase from the PSA Seller approximately 88 acres of real property (the “Property”) located in Clinton, Mississippi, and all improvements, fixtures and personal property situated on the Property.

Under the terms of the Agreements, the Buyer will pay $2,187,500 at the closing of the transactions contemplated by the MIPA and $700,000 at the closing of the transactions contemplated by the PSA, for a total aggregate consideration of $2,887,500. Closing is subject to satisfaction or waiver of certain customary mutual closing conditions. In connection with the Buyer's entry into the Agreements, the Buyer also entered into a Construction Management Services Agreement dated September 16, 2024 (the "CMSA") with Beast Power, Inc. (the "Construction Manager") pursuant to which the Buyer has engaged the Construction Manager to manage the completion of the construction of 16.5 megawatts of bitcoin mining facilities on the Property (the "Project") for aggregate consideration of up to $2,887,500, subject to adjustment as set forth in the CMSA and contingent upon the achievement of certain project milestones, as set forth in the MIPA and CMSA.

The foregoing description of the Agreements and the transactions contemplated thereby do not purport to be complete and is qualified in its entirety by reference to the full text of the Agreements, copies of which are attached hereto as Exhibit 10.1 through 10.3, and incorporated herein by reference.

Item 7.01 Regulation FD Disclosure.

On September 17, 2024, the Company issued a press release announcing the entry into the Agreements and the transactions contemplated thereby. A copy of this press release is attached as Exhibit 99.1 and is being furnished with this Current Report on Form 8-K.

Item 9.01 Financial Statements and Exhibits.

(d) Exhibits


Exhibit No.	Description
10.1*	Membership Interest Purchase Agreement, dated September 16, 2024 by and between Eyas Investment Group Limited and CSRE Properties Mississippi, LLC
10.2*	Real Estate Purchase and Sale Agreement, dated September 16, 2024 by and between Makerstar Capital, Inc. and CSRE Properties Mississippi, LLC
10.3*	Construction Management Services Agreement, dated September 16, 2024 by and between Beast Power, Inc. and CSRE Properties Mississippi, LLC
99.1	Press Release, dated as of September 17, 2024 (furnished herewith)
104	Cover Page Interactive Data File (embedded within the Inline XBRL document)

* Certain schedules and other similar attachments to this exhibit have been omitted from this filing pursuant to Item 601(a)(5) of Regulation S-K. The registrant will provide a copy of such omitted documents to the Securities and Exchange Commission upon request.

SIGNATURES

Pursuant to the requirements of the Securities Exchange Act of 1934, the registrant has duly caused this report to be signed on its behalf by the undersigned hereunto duly authorized.


			CLEANSPARK, INC.

Date:	September 17, 2024	By:	/s/ Zachary Bradford
			Name: Zachary Bradford Title: Chief Executive Officer

MEMBERSHIP INTEREST PURCHASE AGREEMENT

This Membership Interest Purchase Agreement (this “Agreement”) dated effective as of September 16, 2024 (the “Effective Date”), by and between Eyas Investment Group Limited, formerly known as Coinmaker Miners Limited, a British Virgin Islands business company (“Seller”), CSRE Properties Mississippi, LLC, a Mississippi limited liability company (“Buyer”) and, solely for purposes of Article VII, Makerstar Capital, Inc., a Delaware corporation (“Guarantor”). Each of the Seller, the Buyer and the Guarantor are referred to individually herein as a “Party” and collectively herein as the “Parties”.

RECITALS

WHEREAS, Seller owns all of the issued and outstanding membership interests (the “Membership Interests”) of Clinton16.5 LLC a Mississippi limited liability company (the “Company”);

WHEREAS, Seller wishes to sell the Membership Interests to Buyer, and Buyer wishes to purchase the Membership Interests from Seller, subject to the terms and conditions of this Agreement; and

WHEREAS, Guarantor is an Affiliate of Seller and will receive a substantial benefit in connection with the transactions contemplated by this Agreement.

NOW THEREFORE, in consideration of the mutual covenants and agreements hereinafter set forth and for other good and valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties hereto, intending to be legally bound, hereby agree as follows:

ARTICLE I
DEFINITIONS

The terms defined in this Article I shall, for all purposes of this Agreement, have the following respective meanings (all terms used in this Agreement that are not defined in this Article I shall have the meanings as set forth elsewhere in this Agreement):

“Action” means any claim, action, cause of action, demand, lawsuit, arbitration, inquiry, audit, notice of violation, proceeding, litigation, citation, summons, subpoena or investigation of any nature, civil, criminal, administrative, regulatory or otherwise, whether at law or in equity.

“Affiliate” of a Person means any other Person that directly or indirectly, through one or more intermediaries, controls, is controlled by, or is under common control with, such Person. The term “control” (including the terms “controlled by” and “under common control with”) means the possession, directly or indirectly, of the power to direct or cause the direction of the management and policies of a Person, whether through the ownership of voting securities, by contract or otherwise.

“Assignment” has the meaning set forth in Section 3.2(a)(i).

“Business” means the Company’s business of providing mining, hardware and hosting services for the bitcoin network and the owning of assets and taking of activities incidental thereto.

“Business Day” means any day except Saturday, Sunday or any other day on which commercial banks located in Mississippi are authorized or required by Law to be closed for business.

“Code” means the Internal Revenue Code of 1986, as amended.

“Confidential Information” means any and all data and information relating to the Company, including, without limitation, information relating to the Company’s cryptocurrency mining facilities, its activities, business, or customers that (i) was disclosed to Seller or of which Seller became aware as a consequence of its ownership of, management or, or other involvement with the Company; (ii) has value to the Company itself; and (iii) is not generally known outside of Seller. “Confidential Information” also includes, without limitation, the following types of information regarding, related to, or concerning the cryptocurrency mining facility: trade secrets; product lists and specifications; data; know how; formulae; compositions; processes; designs; sketches; graphs; drawings; samples; inventions and ideas; past, current and planned research and development; current and planned sales and marketing methods and processes; loyalty program information; customer lists, current and anticipated customer requirements; price lists and pricing policies; market studies (including analysis of new markets and locations); business plans; improvements; information and competitive strategies; historical financial statements; financial projections and budgets; historical and projected sales; capital spending budgets and plans; the names and backgrounds of key personnel, contractors, agents, suppliers and potential suppliers; personnel training and related techniques and materials; purchasing methods and related techniques; information regarding competitors; and any and all notes, analysis, compilations, studies, summaries and other material prepared by or for Seller containing or based, in whole or in part, upon any information included in the foregoing. “Confidential Information” also includes combinations of information or materials which individually may be generally known outside of the Seller, but for which the nature, method, or procedure for combining such information or materials is not generally known outside of Seller. In addition to data and information relating to the cryptocurrency mining facility, “Confidential Information” also includes any and all data and information relating to or concerning a third party that otherwise meets the definition set forth above, that was provided or made available to Seller by such third party, and that the Seller has a duty or obligation to keep confidential. This definition does not limit any definition of “confidential information” or any equivalent term under state or federal law. “Confidential Information” does not include information that (i) has become generally known by and available to the public by the act of one who has the right to disclose such information without violating any right or privilege of Buyer, and (ii) that is otherwise in the public domain or generally known in the crypto mining industry other than by violation of any confidentiality agreement or similar obligation.

“Contingent Payments” means the First Payment, the Second Payment and the Final Payment, as such terms are defined in the Construction Management Services Agreement.

“Construction Management Services Agreement” means that certain construction management services agreement between Buyer and Seller in the form attached hereto as Exhibit A.

“Contracts” means all contracts, purchasing orders and agreements, leases, deeds, mortgages, licenses, instruments, notes, commitments, undertakings, indentures, joint ventures and all other agreements, commitments and legally binding arrangements, whether written or oral.

“Disclosure Schedules” means the Disclosure Schedules delivered by Seller concurrently with the execution and delivery of this Agreement.

“Encumbrance” means any charge, claim, preemptive right, pledge, condition, equitable interest, lien (statutory or other), option, security interest, mortgage, easement, encroachment, right of way, right of first refusal, or restriction of any kind, including any restriction on use, voting, transfer, receipt of income or exercise of any other attribute of ownership.

“Entergy” means Entergy Mississippi, LLC.

“Environmental Claim” means any Action, Governmental Order, lien, fine, penalty, or, as to each, any settlement or judgment arising therefrom, by or from any Person alleging Liability of whatever kind or nature (including Liability or responsibility for the costs of enforcement proceedings, investigations, cleanup, governmental response, removal or remediation, natural resources damages, property damages, personal injuries, medical monitoring, penalties, contribution, indemnification and injunctive relief) arising out of, based on or resulting from: (a) the presence, Release of, or exposure to, any Hazardous Materials; or (b) any actual or alleged non-compliance with any Environmental Law or term or condition of any Environmental Permit.

“Environmental Law” means any applicable Law, and any Governmental Order or binding agreement with any Governmental Authority: (a) relating to pollution (or the cleanup thereof) or the protection of natural resources, endangered or threatened species, human health or safety, or the environment (including ambient air, soil, surface water or groundwater, or subsurface strata); or (b) concerning the presence of, exposure to, or the management, manufacture, use, containment, storage, recycling, reclamation, reuse, treatment, generation, discharge, transportation, processing, production, disposal or remediation of any Hazardous Materials.

“Environmental Notice” means any written directive, notice of violation or infraction, or notice respecting any Environmental Claim relating to actual or alleged non-compliance with any Environmental Law or any term or condition of any Environmental Permit.

“Environmental Permit” means any Permit, letter, clearance, consent, waiver, closure, exemption, decision or other action required under or issues, granted, given, authorized by or made pursuant to Environmental Law.

“ERISA” means the Employee Retirement Income Security Act of 1974, as amended.

“ERISA Affiliate” means each entity that is treated as a single employer with the Company for purposes of Code § 414.

“Excluded Liability” means any Liability of the Company arising from any business, operation, activity, property or other asset conducted or owned prior to the Closing.

“Governmental Authority” means any federal, state, local or foreign government or political subdivision thereof, or any agency or instrumentality of such government or political subdivision, or any self-regulated organization or other non-governmental regulatory authority or quasi-governmental authority (to the extent that the rules, regulations or orders of such organization or authority have the force of Law), or any arbitrator, court or tribunal of competent jurisdiction.

“Governmental Order” means any order, court opinion, writ, judgment, injunction, decree, stipulation, determination or award entered by or with any Governmental Authority.

“Hazardous Materials” means: (a) any material, substance, chemical, waste, product, derivative, compound, mixture, solid, liquid, mineral or gas, in each case, whether naturally occurring or manmade, that is hazardous, acutely hazardous, toxic, or words of similar import or regulatory effect under Environmental Laws; and (b) any petroleum or petroleum-derived products, radon, radioactive materials or wastes, asbestos in any form, lead or lead-containing materials, urea formaldehyde foam insulation, per- and polyfluoroalkyls, and polychlorinated biphenyls.

“Indebtedness” of any Person means, without duplication, (i) the principal and accrued and unpaid interest, prepayment and redemption premiums or penalties (if any), unpaid fees or expenses and other monetary obligations in respect of (A) indebtedness of such Person for money borrowed and (B) indebtedness evidenced by notes, debentures, bonds or other similar instruments for the payment of which such Person is responsible or liable; (ii) all obligations of such Person issued or assumed as the deferred purchase price of property, all conditional sale obligations of such Person and all obligations of such Person under any title retention agreement; (iii) all obligations of such Person under leases required to be capitalized in accordance with historical practices; (iv) all obligations of such Person for the reimbursement of any obligor on any letter of credit, banker’s acceptance or similar credit transaction; (v) all obligations of such Person under interest rate or currency swap transactions (valued at the termination value thereof); (vi) all obligations of the type referred to in clauses (i) through (v) of any Persons for the payment of which such Person is responsible or liable, directly or indirectly, as obligor, guarantor, surety or otherwise, including guarantees of such obligations; and (vii) all obligations of the type referred to in clauses (i) through (vi) of other Persons secured by (or for which the holder of such obligations has an existing right, contingent or otherwise, to be secured by) any Encumbrance on any property or asset of such Person (whether or not such obligation is assumed by such Person).

“Indemnified Taxes” means (a) all Taxes of the Seller; (b) all Taxes of Company, or relating to the Business of the Company, for all Pre-Closing Tax Periods; (c) all Taxes of any member of an affiliated, consolidated, combined or unitary group of which the Company (or any predecessor of the Company) is or was a member on or prior to the Closing Date by reason of a liability under Treasury Regulation Section 1.1502-6 or any comparable provisions of foreign, state or local Law; (d) any and all Taxes of any Person imposed on the Company arising under the principles of transferee or successor liability or by contract, relating to an event or transaction occurring before the Closing Date; (e) any withholding Taxes imposed in connection with the

transaction contemplated by this Agreement; (f) any Transfer Taxes; and (g) any Losses resulting from an increase in post-Closing Tax Liability or decrease in Tax attribute resulting from a challenge or disallowance of the allocation of the Purchase Price between the Membership Interests purchased pursuant to this Agreement and the real estate purchased pursuant to the Real Estate Purchase Agreement.

“Intellectual Property” means (i) all inventions (whether patentable or unpatentable and whether or not reduced to practice), all improvements thereto, and all patents and patent applications, together with all reissuances, continuations, continuations-in-part, revisions, extensions, and reexaminations thereof, (ii) all trademarks, service marks, trade dress, logos, trade names, domain names, social media handles or accounts, and corporate names, together with all translations, adaptations, derivations, and combinations thereof and including all goodwill associated therewith, and all applications, registrations and renewals in connection therewith, (iii) all copyrights, and all applications, registrations, and renewals in connection therewith, (iv) all trade secrets and confidential business information (including ideas, research and development, know-how, formulas, compositions, manufacturing and production processes and techniques, designs, drawings, specifications, technical data, customer and supplier lists, pricing and cost information, and business and marketing plans and proposals), (v) all computer software, (vi) all database rights, (vii) all design rights and registered designs and all documentation and media constituting or describing any of the foregoing and all copies and tangible embodiments thereof (in whatever form or medium and whether or not any of the foregoing is registered), and (viii) all other proprietary rights, including all moral rights, pertaining to any product or service designed, manufactured, sold, distributed, marketed, used, performed, employed or exploited, and all rights or forms of protection of a similar nature or having equivalent or similar effect to any of those which may subsist anywhere in the world, owned by or registered in the name of any Person or in which any Person has any rights, licenses or immunities.

“Knowledge of Seller” or “Seller’s Knowledge” or any other similar knowledge qualification, means the knowledge of any director or officer of Seller, after reasonable and due inquiry.

“Law” means any statute, law, ordinance, regulation, rule, code, order, constitution, treaty, common law, judgment, decree, other requirement or rule of law of any Governmental Authority.

“Liability” means the amount of any actual liability or obligation of whatever kind or nature (whether known or unknown, whether asserted or unasserted, whether absolute or contingent, whether accrued or unaccrued, whether liquidated or unliquidated, and whether due or to become due), including any liability for Taxes.

“Losses” means losses, damages, Taxes, Liabilities, deficiencies, judgments, interest, awards, penalties, fines, costs or expenses of whatever kind, including reasonable attorneys’ fees and the cost of enforcing any right to indemnification hereunder or under any other Transaction Document and the cost of pursuing any insurance providers.

“Material Adverse Effect” means any effect, change, event, or circumstance that, individually or together with any other effects, changes events, or circumstances, has or would

reasonably be expected to have a material adverse impact on the Company or its assets, operations, or condition of its business in any manner.

“Membership Interests” has the meaning set forth in the Recitals.

“Ordinary Course of Business” means consistent with the past, lawful practice of the Business by the Company and, in any event, in a manner no less than as necessary to ensure compliance with Law in all material respects.

“Organizational Document” means, relative to any Person that is not an individual, its certificate of incorporation, its certificate of formation, its certificate of partnership, its by-laws, its partnership agreement, its limited liability company agreement, its memorandum or articles of association, share designations or similar organization documents and all shareholder agreements, voting trusts and similar arrangements applicable to any of its authorized equity securities, as applicable.

“Permits” means all permits, licenses, franchises, approvals, authorizations, registrations, certificates, variances and similar rights obtained, or required to be obtained, from Governmental Authorities.

“Person” means an individual, corporation, partnership, joint venture, limited liability company, Governmental Authority, unincorporated organization, trust, association or other entity.

“Power Requirement” has the meaning set forth in Section 4.21.

“Pre-Closing Tax Period” means any taxable period ending on or before the Closing Date and, with respect to any taxable period beginning before and ending after the Closing Date, the portion of such taxable period ending on and including the Closing Date.

“Premises” means the real property in Clinton, Mississippi, having addresses known as 1840 N. Frontage Road, Clinton, MS, Parcel Map No. 2980-157, inclusive of the 2.51 acre strip of land east of the transmission line, and the 5 acre parcel on Industrial Park Drive, Clinton, MS, Parcel Map No. 2890-84-1.

“Real Estate Purchase Agreement” means that certain Real Estate Purchase and Sale Agreement, dated as of the date hereof, by and between Guarantor and Buyer or its Affiliate pursuant to which Buyer or its Affiliate acquires the Premises from Seller.

“Release” means any actual or threatened release, spilling, leaking, pumping, pouring, emitting, emptying, discharging, injecting, escaping, leaching, dumping, abandonment, disposing or allowing to escape or migrate into or through the environment (including, without limitation, ambient air (indoor or outdoor), surface water, groundwater, land surface or subsurface strata or within any building, structure, facility or fixture).

“Representative” means, with respect to any Person, any and all directors, officers, employees, consultants, financial advisors, counsel, accountants and other agents of such Person.

“Tax Return” means any return, declaration, report, claim for refund, information return or statement or other document relating to Taxes, including any schedule or attachment thereto, and including any amendment thereof.

“Taxes” means (a) all U.S. federal, state, local, or foreign. income, franchise, profits or gross receipts, ad valorem, value added, capital gains, sales, goods and services, use, real or personal property, unclaimed or abandoned property liability or obligation (whether delineated as a tax), escheat liability or obligation (whether delineated as a tax), capital stock, capital, alternative minimum, license, registration, branch, payroll, estimated, withholding, employment, excise, severance, privilege, stamp, occupation, premium, windfall profits, environmental, social security (or similar), unemployment compensation, disability, transfer, gains and any other taxes (and any levies, fees, imposts, duties, governmental charges, assessments, obligations or tariffs in the nature of a tax) of any kind whatsoever, together with any interest, fines, assessments, penalties or additions to tax imposed in connection therewith or with respect thereto; and any interest in respect of such additions or penalties and (b) any liability for the payment of any items described in clause (a) above as a result of being (or ceasing to be) a member of an affiliated, consolidated, combined, unitary, or other group for Tax purposes (or being included (or being required to be included) in any Tax Return related to such group), as a transferee or successor, by Contract, pursuant to any Law or otherwise.

“Transaction Documents” means this Agreement, the Real Estate Purchase Agreement, the Construction Management Services Agreement, the Assignment and the Officer’s Certificate.

“Transaction Fees” means, without duplication, the following unpaid fees, expenses and other similar amounts that have been or are expected to be incurred on or prior to the Closing Date on behalf of the Seller or Buyer: (i) the fees and disbursements of, or other similar amounts charged by, counsel to the Seller or Buyer, as applicable; (ii) the reasonable fees and expenses of, or other similar amounts charged by, any accountants, agents, financial advisors, consultants and experts employed by the Seller or the Buyer, as applicable; and (iii) all other costs or other expenses incurred by the Seller or Buyer, as applicable, in connection with or as a result of the transactions contemplated by this Agreement.

“Treasury Regulations” means the regulations promulgated under the Code, as amended and in effect from time to time.

ARTICLE II
PURCHASE AND SALE

Section 2.1

Purchase and Sale. Subject to the terms and conditions set forth herein, at the Closing, Seller shall sell to Buyer, and Buyer shall purchase from Seller, all of the Membership Interests, free and clear of all Encumbrances, for the consideration specified in Section 2.2 below.

Section 2.2

Purchase Price. The aggregate Purchase Price for the Membership Interests shall be Two Million One Hundred Eighty-Seven Thousand Five Hundred Dollars ($2,187,500.00) (the “Purchase Price”). Buyer shall pay the Purchase Price at Closing in cash by wire transfer of immediately available funds to a United States bank account designated in writing by Seller.

Section 2.3

Right of Setoff. Pursuant to Section 7.7(b) of this Agreement, Buyer shall have the right in its sole discretion to satisfy all or any part of any claim for Losses by setting off such Losses against any of the Contingent Payments.

Section 2.4

Withholding Taxes. Notwithstanding anything to the contrary herein, Buyer shall be entitled to deduct and withhold from the Purchase Price or any other amounts payable under this Agreement such amounts that Buyer may be required to deduct and withhold with respect to the making of such payment under the Code, or any other applicable Law. All such deducted or withheld amounts shall be treated as having been paid to Seller hereunder.

Section 2.5

Intended Tax Treatment; Purchase Price Allocation.

(a)

The Buyer and Seller intend that the purchase of the Membership Interests shall be treated for U.S federal (an applicable state and local) income Tax purposes, as a purchase and sale of the assets of the Company.

(b)

The Buyer and Seller will allocate the Purchase Price and other items properly taken into account for U.S. federal income tax purposes, including Contingent Payments, among the assets of the Company in accordance with the principles set forth in Section 1060 of the Code and the Treasury Regulations thereunder. (the “Allocation”). Buyer will prepare the Allocation within 120 days following the Closing and provide a copy of such Allocation to Seller promptly thereafter for Seller’s review and comment. Within 30 days after its receipt of Buyer’s proposed Allocation, Seller may propose to Buyer any comments thereto. If Seller does not provide Buyer with any proposed changes to the Allocation within such 30-day period, the Allocation shall become final and binding on the parties. If Seller proposes comments to Buyer’s proposed Allocation within such 30-day period, then the parties shall act in good faith to address and resolve any such comments within 30 days of receipt of Seller’s proposed changes. If the parties resolve all such disputed items, then Buyer shall furnish Seller with a final Allocation consistent with such agreed-upon resolution as soon as practicable. If the parties do not resolve any disputed item, the item in question shall be resolved promptly by an impartial nationally recognized firm of independent certified public accountants (other than Seller’s accountants or Buyer’s accountants) that is mutually selected by Buyer and Seller in accordance with Section 1060 of the Code and the Treasury Regulations thereunder, which resolution shall be final and binding on the parties. The costs of the independent accountants shall be borne equally by Buyer and Seller. In case of any adjustment to the Purchase Price (or any other item of consideration for federal income Tax purposes) requiring an amendment to the Allocation, the parties will amend the Allocation in accordance with the principles set forth in Section 1060 of the Code and the Treasury Regulations thereunder. The parties agree that they shall file and shall cause their Affiliates to file their Tax Returns (including IRS Form 8594) in a manner consistent with the Allocation as finally determined under this Section 2.5(b), and no party shall voluntarily take a position, inconsistent with such Allocation on any Tax Return, in any refund claim, in any proceeding or otherwise with respect to Taxes or Tax Returns, unless required to do so pursuant to a “determination” (as defined in Section 1313(a) of the Code or any comparable or similar election under applicable state, local, foreign or other Law); provided, however, that no party shall be unreasonably impeded in its ability and discretion to negotiate, compromise and/or settle any Tax audit, claim or similar proceedings in connection with the Allocation. If there is an increase or decrease in the consideration within the meaning of Treasury Regulations Section

1.1060-1(e)(1)(ii)(B) after the parties have filed the IRS Form 8594, the parties shall revise the Allocation in a manner consistent with Section 1060 of the Code, the Treasury Regulations thereunder and such revised allocation shall become the final Allocation for purposes of this Agreement.

ARTICLE III

CLOSING

Section 3.1

Closing Date. The closing of the transactions contemplated by this Agreement (the “Closing”) shall take place simultaneously with the execution of this Agreement on the date of this Agreement or at such other time as the Parties hereto agree in writing (such date, the “Closing Date”). The Closing shall take place via the transmission to the respective offices of legal counsel for the Parties via e-mail in portable document format (.pdf) with due confirmation of all requisite Transaction Documents (including but not limited to those Closing deliveries described at Section 3.2 below) duly executed where requested, or at such other place as may be mutually agreed upon by the Parties hereto in writing. The consummation of the transactions contemplated by this Agreement shall be deemed to occur at 12:01 a.m. Eastern Time on the Closing Date.

Section 3.2

Closing Deliveries. At Closing, the respective Parties shall take the following actions:

(a)

Documents to be Provided by Seller: Seller agrees to (or to cause the Company to, as applicable) deliver the following documents to Buyer, in the form and substance reasonably satisfactory to Buyer, duly executed as appropriate:

(i)

Assignment. An assignment agreement, duly executed by Seller, transferring the Membership Interests from Seller to Buyer, in form and substance satisfactory to Buyer (the “Assignment”);

(ii)

Transaction Documents. All other Transaction Documents and all other agreements, documents, instruments or certificates required to be delivered by Seller at or prior to the Closing pursuant to this Agreement;

(iii)

Good Standing Certificate. A good standing certificate of the Company from its jurisdiction of organization dated as of a recent date prior to Closing;

(iv)

Power Requirement. Evidence reasonably satisfactory to the Buyer that the Power Agreements to satisfy the Power Requirement have been delivered to Buyer.

(v)

Entergy Consent. If required, receipt of the consent of Entergy under the Power Agreements to the transactions contemplated by this Agreement.

(vi)

Other Documents. Such other documents as Buyer may reasonably request, from time to time, to conclude and carry out the sale, conveyance, transfer and assignment of Seller’s rights in and to the Membership Interests and to conclude the other transactions contemplated under this Agreement.

(b)

Documents to be Provided by Buyer: Buyer agrees to deliver the following documents, in the form and substance reasonably satisfactory to Seller, duly executed as appropriate:

(i)

Payment of Purchase Price. The Purchase Price in the amount and form as required by Section 2.3 above; and

(ii)

Transaction Documents. All other Transaction Documents and all other agreements, documents, instruments or certificates required to be delivered by Buyer at or prior to the Closing pursuant to this Agreement.

ARTICLE IV

REPRESENTATIONS AND WARRANTIES OF SELLER
CONCERNING THE COMPANY

Except as set forth in the correspondingly numbered Section of the Disclosure Schedules, Seller represents and warrants to Buyer as follows:

Section 4.1

Authority of Seller. Seller has full power and authority to enter into this Agreement and the other Transaction Documents to which Seller is a party, to carry out its obligations hereunder and thereunder, and to consummate the transactions contemplated hereby and thereby. This Agreement has been duly executed and delivered by Seller, and (assuming due authorization, execution and delivery by each other party thereto) this Agreement constitutes a legal, valid and binding obligation of Seller enforceable against Seller in accordance with its terms except to the extent that enforceability may be limited by applicable bankruptcy, fraudulent conveyance, reorganization, insolvency, moratorium or other similar Laws relating to creditors’ rights generally, and general equitable principles whether considered in a proceeding at law or in equity (collectively, the “Enforceability Exceptions”). When each other Transaction Document to which Seller is or will be a party has been duly executed and delivered by Seller (assuming due authorization, execution and delivery by each other party thereto), such Transaction Document will constitute a legal and binding obligation of Seller enforceable against it in accordance with its terms, except to the extent that enforceability may be limited by the Enforceability Exceptions.

Section 4.2

Organization, Authority and Qualification of Company. The Company is a Mississippi limited liability company duly organized, validly existing and in good standing under the Laws of the State of Mississippi and has full limited liability company power and authority to own, operate or lease the properties and assets now owned, operated or leased by it and to carry on its business as currently conducted. The Company is duly licensed or qualified to do business as a foreign entity and is in good standing under the laws of each jurisdiction under which such licensing or qualification is necessary. All limited liability company actions taken by the Company in connection with this Agreement and the other Transaction Documents will be duly authorized on or prior to the Closing. Section 4.2 of the Disclosure Schedules lists the board of directors, managers, and officers, as the case may be, of the Company. Seller has made available to Buyer copies of all Organizational Documents, the minute book, and equity record books for the Company, each of which is correct and complete in all material respects. The Company is not in default under or in violation of any provision of its Organizational Documents in any material respect.

Section 4.3

Capitalization

(a)

Seller is the record and beneficial owner of and has good and valid title to the Membership Interests, free and clear of all Encumbrances. The Membership Interests constitute 100% of the total issued and outstanding membership interests in the Company. The Membership Interests have been duly authorized and are validly issued, fully-paid, and non-assessable. Upon consummation of the transactions contemplated by this Agreement, Buyer shall own all of the Membership Interests, free and clear of all Encumbrances.

(b)

The Membership Interests were issued in compliance with applicable Laws. The Membership Interests were not issued in violation of any Organizational Documents of the Company or any other agreement, understanding, arrangement, or commitment to which Seller or the Company is a party and are not subject to or in violation of any preemptive or similar rights of any Person.

(c)

There are no authorized or outstanding (i) subscriptions, options, warrants, calls, rights of first refusal or other rights of any character to acquire equity or debt interests from the Company or Seller or any phantom equity, equity appreciation rights or other contract rights intended to provide an economic return based on changes in the value of any debt or equity securities of the Company or Seller, (ii) rights or Contracts to which the Company or Seller is a party requiring, or convertible securities of the Company or Seller outstanding which upon conversion would require, the issuance of any equity interests of the Company or Seller or other securities convertible into equity interests of the Company or Seller, or (iii) contract rights or options pursuant to which the Company or Seller is required to or have the right to redeem, purchase or otherwise reacquire any equity securities, or other instrument convertible or exercisable into equity securities, of the Company or Seller. There are no Contracts to which the Company or Seller is a party with respect to: (x) the voting of any equity of the Company or Seller (including any buy-sell agreement, preemptive right, voting trust or agreement, equityholders agreement, proxy or director or manager nomination rights); (y) the transfer of or transfer restrictions on any equity interests of the Company or Seller; or (z) the granting of any other rights in respect of any equity interests of the Company or Seller (e.g., equity appreciation rights).

Section 4.4

No Subsidiaries; No Other Arrangements. The Company does not have any subsidiaries and does not own or hold the right to acquire or control any equity security or other interest of any other corporation, partnership, limited liability company or other business entity. The Company is not a participant in any joint venture, partnership, limited liability company or similar arrangement.

Section 4.5

No Conflicts; Consents. The execution, delivery and performance by Seller of this Agreement and the other Transaction Documents to which it is a party, and the consummation of the transactions contemplated hereby and thereby, do not and will not (a) conflict with or result in a violation or breach of, or default under, any provision of the Organizational Documents of the Seller or the Company; (b) conflict with or result in a violation or breach in any respect of any provision of any Law or Governmental Order applicable to Seller or the Company; (c) require the consent, notice or other action by any Person under any Contract to which Seller or the Company is a party; or (d) result in the creation or imposition of any Encumbrance on any properties or assets of the Company. No consent, approval, Permit, Governmental Order,

declaration or filing with, or notice to, any Governmental Authority is required by or with respect to Seller or the Company in connection with the execution and delivery of this Agreement and the other Transaction Documents and the consummation of the transactions contemplated hereby and thereby. Neither Seller nor the Company has received any written or oral notice from any Governmental Authority indicating that such Governmental Authority would oppose or not promptly grant or issue its consent or approval, if requested, with respect the Transaction Documents or any of the transactions contemplated thereunder.

Section 4.6

Contracts. Section 4.6 of the Disclosure Schedules sets forth each Contract to which the Company is a party (collectively, the “Assumed Contracts” and, individually, an “Assumed Contract”). Each Assumed Contract is in full force and effect and is a legal, valid and binding obligation of Company enforceable in accordance with its terms (and will continue to be in full force and effect following the consummation of the transactions contemplated hereby). Neither the Company nor, to Knowledge of Seller, any other party thereto is in breach of or default under (or is alleged to be in breach of or default under), any Assumed Contract. There has not been any notice or threat to terminate any Assumed Contract. No event has occurred which (with or without notice or lapse of time or both) constitutes a breach or default in any material respect of, or permits termination, modification or acceleration of payment or requires any payment under, any Assumed Contract. Correct and complete copies of (i) each Assumed Contract, (ii) all material correspondence related to the Assumed Contracts, and (iii) all material documents relating to the Assumed Contracts, all licenses, all environmental assessment reports (such as Phase I and Phase II reports) and any other environmental studies in Seller’s possession relating to any Assumed Contracts have been made available to Buyer.

Section 4.7

Undisclosed Liabilities. As of the Closing Date the Company will have no Indebtedness or other Liabilities.

Section 4.8

Assets.

(a)

Section 4.8 of the Disclosure Schedules sets forth a list of all of the Company’s assets, including furniture, fixtures, machinery, equipment, vehicles and other items of tangible personal property and other assets used in the Business (collectively, the “Assets”). The Company is in possession of and has good and valid title to, or, as applicable, a valid and existing leasehold interest in or license to such Assets. Such Assets (i) are free and clear of all Encumbrances other than Permitted Encumbrances; and (ii) include all the tangible and intangible assets and rights required for the operation of the Business as has been and as is currently being conducted by the Company. During the past five (5) years, there has not been any significant interruption of the Business due to inadequate maintenance or obsolescence of such properties and assets (including leasehold interests). There are no assets of any kind or nature whatsoever used in the Business that will not be owned or available for use by the Company immediately after the Closing on the same terms as the date of this Agreement.

(b)

The furniture, fixtures, machinery, equipment, vehicles and other items of tangible personal property of the Company are in good operating condition and repair (including with respect to the performance of reasonable preventative maintenance), are free of defects that affect their current use by the Company in the conduct of its normal operations as has been and as is currently being conducted, and are adequate for the uses to which they are being put, and none

of such furniture, fixtures, machinery, equipment, vehicles and other items of tangible personal property is in need of maintenance or repairs except for ordinary, routine maintenance and repairs that are not material in nature or cost.

(c)

No other Person other than the Company owns, licenses, or leases any equipment or other tangible assets or properties used in or necessary to the operation of the Business.

Section 4.9

Real Property.

(a)

After giving effect to the Real Estate Purchase Agreement, the Company does not own any real property.

(b)

The Company does not lease any real property.

Section 4.10

Legal Proceedings; Governmental Orders; Contracts.

(a)

There are no Actions pending or, to Seller’s Knowledge, threatened against or by Seller or the Company: (a) relating to or affecting the Membership Interests, the Company or its business or assets; or (b) that challenge or seek to prevent, enjoin or otherwise delay the transactions contemplated by this Agreement or any Transaction Document.

(b)

There are no outstanding Governmental Orders against, relating to or affecting the Company, its business or its assets.

Section 4.11

Compliance with Laws; Permits.

(a)

The Company has complied in all material respects, and is now complying in all material respects, with all Laws applicable to it or its properties, or assets.

(b)

Neither Seller nor the Company has received any written communication from any Governmental Authority or other Person that remains unresolved as of the Effective Date that alleges that the Company is not in material compliance with any Laws. All Company Permits are in good standing, valid and in full force and effect.

Section 4.12

Environmental Matters. The Company has not, and Seller has not, received from any Person any: (i) Environmental Notice or Environmental Claim; or (ii) written request for information pursuant to Environmental Law, which, in each case, either remains pending or unresolved, or is the source of ongoing obligations or requirements as of the Closing Date.

Section 4.13

Taxes.

(a)

The Company is currently treated as a “disregarded entity” for U.S. federal income Tax purposes pursuant to Treasury Regulation Section 301.7701-3(b)(1)(ii) and no election has been made (or is pending) to change such treatment.

(b)

All Tax Returns required to be filed on or before the Closing Date by the Company have been timely filed. Such Tax Returns are true, complete and correct in all respects. All Taxes due and owing by the Company (whether or not shown on any Tax Return) have been timely paid. No extensions or waivers of statutes of limitations have been given or requested with respect to any Taxes of the Company. Seller has delivered to Buyer copies of all Tax Returns and examination reports of the Company and statements of deficiencies assessed against, or agreed to by, the Company, for all Tax periods.

(c)

The Company has withheld and paid each Tax required to have been withheld and paid in connection with amounts paid or owing to any employee, independent contractor, creditor, customer, member or other party, and complied in all respects with all information reporting and backup withholding provisions of applicable Law.

(d)

No written or oral claim has been made by any taxing authority in any jurisdiction where the Company does not file Tax Returns that it is, or may be, subject to Tax by that jurisdiction.

(e)

All deficiencies asserted, or assessments made, against the Company as a result of any examinations by any taxing authority have been fully paid or resolved. The Company is not a party to any Action by any taxing authority. There are no pending or threatened Actions by any taxing authority.

(f)

There are no Encumbrances for Taxes upon the assets of the Company.

(g)

The Company is not a party to, or bound by, any Tax indemnity, Tax sharing or Tax allocation agreement.

(h)

No private letter rulings, technical advice memoranda or similar agreement or rulings have been requested, entered into or issued by any taxing authority with respect to the Company.

(i)

The Company has not been a member of an affiliated, combined, consolidated or unitary Tax group for Tax purposes. The Company has no Liability for Taxes of any Person (other than the Company) under Treasury Regulations Section 1.1502-6 (or any corresponding provision of state, local or foreign Law), as transferee or successor, by contract or otherwise.

(j)

Neither the Company nor the Buyer will be required to include an item of income, or exclude a an item of deduction, for any period after the Closing Date with respect to the Company as a result of (i) an installment sale transaction occurring on or before the Closing governed by Section 453 of the Code (or any similar provision of state, local or non-U.S. Laws); (ii) a transaction occurring on or before the Closing reported as an open transaction for U.S. federal income Tax purposes (or any similar doctrine under state, local or non-U.S. Laws); (iii) any prepaid amounts received or paid on or prior to the Closing Date or deferred revenue realized on or prior to the Closing Date; (iv) a change in method of accounting with respect to a Pre-Closing Tax Period (or an impermissible method used in a Pre-Closing Tax Period); or (v) a Contract entered into with any Governmental Entity (including a “closing agreement” under Section 7121 of the Code or any “gain recognition agreement” entered into under Section 367 of the Code) on or prior

to the Closing relating to Tax matters. The Company has no “long-term contracts” that are subject to a method of accounting provided for in Section 460 of the Code or has any deferred income pursuant to IRS Revenue Procedure 2004-34, Treasury Regulation Section 1.451-5, Section 455 of the Code, or Section 456 of the Code (or any corresponding provision of state or local Law).

(k)

The Company has not been a “distributing corporation” or a “controlled corporation” in connection with a distribution described in Section 355 of the Code occurring during the two (2) year period ending on the date of this Agreement.

(l)

The Company is not, and has not been, a party to, or a promoter of, a “reportable transaction” within the meaning of Section 6707A(c)(1) of the Code and Treasury Regulations Section 1.6011-4(b).

(m)

The Company is not (and never has been during the applicable period specified in Section 897(c)(1)(A)(ii) of the Code) a “United States real property holding corporation” and does not own any “United States real property interests”, each within the meaning of Section 897(c) of the Code.

(n)

The Company has been a resident in its applicable country of organization for Tax purposes and has not had a permanent establishment outside the United States or been treated as a resident of or as engaging in a trade or business in any other country for income Tax purposes.

(o)

The Company has not requested or received “employee retention credits” under Section 2301 of the Coronavirus Aid, Relief, and Economic Security Act of 2020.

Section 4.14

Books and Records. The books and records of the Company, all of which have been delivered to Buyer, are complete and correct in all material respects and have been maintained in accordance with past practice.

Section 4.15

Brokers. No broker, finder or investment banker is entitled to any brokerage, finder’s or other fee or commission in connection with the transactions contemplated by this Agreement or any other Transaction Document based upon arrangements made by or on behalf of Seller or the Company.

Section 4.16

Employees. The Company does not have and has never had any employees.

Section 4.17

Employee Benefits. Neither the Company nor its ERISA Affiliates have ever (i) maintained, contributed to or participated in an employee benefit plan (including all such plans within the meaning of Section 3(3) of ERISA), program or arrangement (including any incentive compensation plan or one that grants equity based awards) for the benefit of any current or former employee, consultant, independent contractor or member of the Company (ii) contributed to, or had any obligation to contribute to, any such plan, including a multiemployer plan as defined in ERISA Section 3(37) and any plan subject to Title IV of ERISA, or (iii) had any Liability with respect to any such plan, contingent or otherwise. The Company has not granted, nor is the Company a party to any contract, agreement, plan or program that grants, any compensation, equity award or bonus that could be deemed “deferred compensation” within the meaning of Section 409A of the Code, and neither the Company nor any ERISA Affiliate has any

Liability to make any payments or issue any equity award or bonus that could be deemed “deferred compensation” within the meaning of Section 409A of the Code other than as disclosed. Except as may be required by applicable law, the Company does not provide health or welfare benefits for any retired or former employee, or their beneficiaries or dependents, and the Company is not obligated to provide health or welfare benefits to any active employee following such employee’s retirement or other termination of service.

Section 4.18

Guaranties. The Company is not a guarantor or otherwise liable for any Liability (including Indebtedness) of any other Person. Neither Seller nor any Affiliate of Seller is a guarantor or otherwise liable for any Liability (including Indebtedness) or Contract of the Company.

Section 4.19

Intellectual Property. The Company neither owns, licenses nor uses any Intellectual Property.

Section 4.20

Bank Accounts. The Company does not own or otherwise maintain any deposit, securities or intermediary accounts of any nature.

Section 4.21

Power Agreements. The agreements set forth on Section 4.21 of the Disclosure Schedules with Entergy (the “Power Agreements”) provide for an aggregate of 16.5 megawatts of power that is available to the Premises (the “Power Requirement”). Entergy has sufficient infrastructure in place on the Premises to support delivery of 16.5 megawatts to the Premises.

ARTICLE V
REPRESENTATIONS AND WARRANTIES OF BUYER

Buyer represents and warrants to Seller as follows:

Section 5.1

Authority. Buyer has full power and authority to enter into this Agreement and the other Transaction Documents to which Buyer is a party, to carry out its obligations hereunder and thereunder, and to consummate the transactions contemplated hereby and thereby. This Agreement has been duly executed and delivered by Buyer, and (assuming due authorization, execution and delivery by each other party thereto) this Agreement constitutes a legal, valid and binding obligation of Buyer enforceable against the Buyer in accordance with its terms, except to the extent that enforceability may be limited by the Enforceability Exceptions. When each other Transaction Document to which Buyer is or will be a party has been duly executed and delivered by Buyer (assuming due authorization, execution and delivery by each other party thereto), such Transaction Document will constitute a legal and binding obligation of Buyer enforceable against it in accordance with its terms, except to the extent that enforceability may be limited by the Enforceability Exceptions.

Section 5.2

No Conflicts; Consents. The execution, delivery and performance by Buyer of this Agreement and the other Transaction Documents to which it is a party, and the consummation of the transactions contemplated hereby and thereby, do not and will not (a) conflict with or result in a violation or breach of any provision of any Law or Governmental Order applicable to Buyer; (b) require the consent, notice or other action by any Person under any Contract to which Buyer is a party or (c) require any consent, permit, Governmental Order, filing

or notice from, with or to any Governmental Authority or any other Person by or with respect to Buyer in connection with the execution and delivery of this Agreement and the Transaction Documents to which Buyer is or will be a party, and the consummation of the transactions contemplated hereby and thereby.

Section 5.3

Section 5.4

No Other Representations and Warranties. Except as otherwise expressly set forth in this Article V, Buyer expressly disclaims any representations or warranties of any kind or nature, express or implied, including any representations or warranties as to the Buyer, its respective businesses and affairs or the transactions contemplated by this Agreement. Except as otherwise expressly set forth in this Article V, neither Buyer nor any of its respective Affiliates, employees, officers, directors or members, has made, and shall not be deemed to have made, any representations or warranties in the materials relating to the business and affairs of the Buyer that have been made available to Seller, including in any presentation of the business and affairs of the Buyer by the management of the Buyer or others in connection with the transactions contemplated hereby, and no statement contained in any of such materials or made in any such presentation shall be deemed a representation or warranty hereunder or otherwise or deemed to be relied upon by Seller in executing, delivering and performing this Agreement and the transactions contemplated hereby.

ARTICLE VI

TAX MATTERS

Section 6.1

Straddle Period. In the case of any taxable period that includes (but does not end on) the Closing Date (a “Straddle Period”), the amount of any Taxes based on or measured by income or receipts of the Company for the Pre-Closing Tax Period shall be determined based on an interim closing of the books as of the close of business on the Closing Date and the amount of other Taxes of the Company for a Straddle Period that relates to the Pre-Closing Tax Period shall be deemed to be the amount of such Tax for the entire taxable period multiplied by a fraction the numerator of which is the number of days in the taxable period ending on the Closing Date and the denominator of which is the number of days in such Straddle Period.

Section 6.2

Cooperation on Tax Matters. The Parties shall cooperate fully, as and to the extent reasonably requested by any other Party, in connection with the filing of Tax Returns and any audit, litigation or other proceeding with respect to Taxes with respect to the Company. Such cooperation shall include the retention and the provision of records and information that are reasonably relevant to any such Tax Returns, audit, litigation or other proceeding. Buyer shall use reasonable commercial efforts to retain all books and records with respect to Tax matters pertinent to the Company relating to any taxable period beginning before the Closing Date until the expiration of the statute of limitations (and, to the extent notified by any other party, any extensions thereof) of the respective taxable periods, and to abide by all record retention agreements entered into with any taxing authority. Buyer and Seller further agree, upon request, to use their best efforts to obtain any certificate or other document from any governmental authority or any other Person

as may be necessary to mitigate, reduce or eliminate any Tax that could be imposed (including, but not limited to, with respect to the transactions contemplated hereby).

Section 6.3

Tax Contests

(a)

If the Buyer or any of its Affiliates receives notice of a Tax audit, controversy or other proceeding relating to the Company (“Tax Contest”) with respect to any taxable period ending on or prior to the Closing Date or the portion through the end of the Closing Date of any Straddle Period, then within ten (10) days after receipt of such notice, the Buyer shall notify the Seller of such notice. The Buyer’s notification to the Seller shall contain factual information describing the Tax Contest in reasonable detail and shall include copies of any notice or other document received from any taxing authority in respect of any such Tax Contest. A failure by the Buyer to give such notice shall not affect Buyer’s right to indemnification hereunder except to the extent that the Seller is materially prejudiced thereby.

(b)

In the case of a Tax Contest that relates to a taxable period ending on or before the Closing Date, the Seller shall have the sole right, at its expense, to control the conduct of the Tax Contest. To the extent the Seller elects to control the Tax Contest, the Seller shall within fifteen (15) days of receipt of the notice of Tax Contest notify the Buyer in writing of its intent to do so, and the Buyer shall reasonably cooperate and shall cause the Company to reasonably cooperate in each phase of such Tax Contest. The Seller may not compromise, settle or resolve any such Tax Contest without obtaining the Buyer’s prior written consent (such consent not to be unreasonably withheld, delayed or conditioned). If the Seller elects not to control the Tax Contest, the Buyer shall assume control of such Tax Contest. and Buyer shall not compromise, settle or resolve any Tax Contest without obtaining the Seller’s prior written consent (such consent not to be unreasonably withheld, delayed or conditioned) (such rights of the Seller, the “Seller’s Rights”). Additionally, in the case of a Tax Contest that relates to a Straddle Period (a “Straddle Period Contest”), the Buyer shall have the right to control such Straddle Period Contest subject to the Seller’s Rights.

Section 6.4

Transfer Taxes. All transfer, documentary, sales, use, stamp, registration, recording and other similar Taxes and fees (including any penalties and interest) that are imposed on any of the parties by any taxing authority in connection with the transactions contemplated by this Agreement (collectively, “Transfer Taxes”) and all expenses of filing Tax Returns with respect to such Taxes shall be borne by Seller. Seller and the Buyer shall cooperate in timely making all filings, returns, reports and forms as necessary or appropriate to comply with the provisions of all applicable Tax Laws in connection with the payment of such Transfer Taxes.

Section 6.5

Tax Sharing Agreements. All Tax sharing agreements or similar contractual obligations and all powers of attorney with respect to the Company shall be terminated prior to the Closing and, after the Closing, the Company shall not be bound thereby or have any liability thereunder.

ARTICLE VII
INDEMNIFICATION

Section 7.1

Survival. The representations and warranties shall survive the Closing and shall remain in full force and effect after the Closing Date for the full period of all applicable statutes of limitations (giving effect to any waiver, mitigation or extension thereof) plus ninety (90) days. All other covenants and agreements of the Parties contained herein shall survive the Closing for the period explicitly specified therein, or if no such period is specified, then until the expiration of the applicable statute of limitations. Notwithstanding the foregoing, any claims asserted in good faith with reasonable specificity (to the extent known at such time) and in writing by notice from the non-breaching Party to the breaching Party prior to the expiration date of the applicable survival period shall not thereafter be barred by the expiration of the relevant representation or warranty and such claims shall survive until finally resolved.

Section 7.2

Indemnification by Seller and Guarantor. Subject to the terms and conditions of this Article VII, from and after the Closing, Seller and Guarantor shall jointly and severally indemnify and defend Buyer and Buyer’s Affiliates (including the Company) and their respective Representatives (collectively, the “Buyer Indemnitees”) against, and shall hold each of them harmless from and against, and shall pay and reimburse each of them for, any and all Losses incurred or sustained by, or imposed upon, Buyer Indemnitees based upon, arising out of, with respect to or by reason of:

(a)

any inaccuracy in or breach of any of the representations or warranties of Seller contained in this Agreement or any other Transaction Document;

(b)

any Indemnified Taxes;

(c)

any Indebtedness or Transaction Fees of the Company as of the Closing;

(d)

any breach or non-fulfillment of any covenant, agreement or obligation to be performed by Seller pursuant to this Agreement or any of the Transaction Documents (including, without limitation, the failure to enter into any other Transaction Documents);

(e)

any acts or omissions of the Company or the Seller prior to the date hereof; and

(f)

any Excluded Liability.

For the sole purpose of determining Losses (and not for determining whether or not any breaches of representations or warranties have occurred), the representation or warranty shall be determined without regard to any materiality, material adverse effect or other similar qualification contained in or otherwise applicable to such representation or warranty.

Section 7.3

Indemnification Procedures. The Party making a claim under this Article VII is referred to as the “Indemnified Party,” and the Party against whom such claims are asserted under this Article VII is referred to as the “Indemnifying Party.”

(a)

Third-Party Claims. If any Indemnified Party receives notice of the assertion or commencement of any Action made or brought by any Person who is not a Party to this Agreement or an Affiliate of a Party to this Agreement or a Representative of the foregoing (a “Third-Party Claim”) against such Indemnified Party with respect to which the Indemnifying

Party is obligated to provide indemnification under this Agreement, the Indemnified Party shall give the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than fifteen (15) calendar days after receipt of such notice of such Third-Party Claim (the “Third-Party Claim Notice”). The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. The Third-Party Claim Notice shall describe the Third-Party Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party.

(b)

Defense of Third-Party Claims. In the case of a Third-Party Claim, the Indemnifying Party shall have the right: (a) to control and conduct any proceedings or negotiations in connection therewith and necessary or appropriate to defend the claim, (b) to take all other reasonable steps or proceedings to settle or defend any such Third-Party Claim; provided, that the Indemnifying Party shall not settle any Third-Party Claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, conditioned, or delayed), and (c) to employ counsel designated by the Indemnifying Party to contest any such Third-Party Claim in the name of the Indemnified Party or otherwise. The Indemnifying Party shall, within fifteen (15) days of receipt of a Third-Party Claim Notice (the “Indemnity Notice Period”), give written notice to the Indemnified Party of its intention to assume the defense of such Third-Party Claim. If the Indemnifying Party does not deliver to the Indemnified Party within the Indemnity Notice Period written notice that the Indemnifying Party shall assume the defense of any such Third-Party Claim, then the Indemnified Party may defend against any such Third-Party Claim in any such manner as it may deem appropriate, provided, that the Indemnified Party shall not settle any such Third-Party Claim without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, conditioned, or delayed. In the event that the Indemnifying Party does assume the defense of such Third-Party Claim, the Indemnified Party shall have the right to fully participate in (but not control) such defense (including with counsel of its choice), at its sole expense, and the Indemnifying Party shall reasonably cooperate with the Indemnified Party in connection with such participation. In the event that either the Indemnifying Party or the Indemnified Party assumes the defense of a Third-Party Claim as provided above (the “Controlling Party”), the non-Controlling Party shall have the right to fully participate (but not control) in such defense (including with counsel of its choice), at its sole expense, and the Controlling Party shall reasonably cooperate with the non-Controlling Party in connection with such participation; provided, however, that Buyer and Seller shall each use its commercially reasonable efforts with respect to any information shared pursuant to this Section 7.3(b) to preserve attorney-client privilege.

(c)

Direct Claims. Any Action by an Indemnified Party on account of a Loss which does not result from a Third-Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than thirty (30) days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been

or may be sustained by the Indemnified Party. The Indemnifying Party shall have thirty (30) days after its receipt of such notice to respond in writing to such Direct Claim. If the Indemnifying Party does not so respond within such thirty (30) day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.

Section 7.4

Payments. Once a Loss is agreed to by the Indemnifying Party or finally adjudicated to be payable pursuant to this Article VII, the Indemnifying Party shall satisfy its obligations within fifteen (15) Business Days following such final, non-appealable adjudication by wire transfer of immediately available funds.

Section 7.5

Tax Treatment of Indemnification Payments. All indemnification payments made under this Agreement shall be treated by the Parties as an adjustment to the Purchase Price for Tax purposes, unless otherwise required by Law.

Section 7.6

Indemnification by Buyer. Subject to the terms and conditions of this Article VII, Buyer shall indemnify and defend Seller and Seller’s Affiliates and their respective Representatives (collectively, the “Seller Indemnitees”) against, and shall hold each of them harmless from and against, and shall pay and reimburse each of them for, any and all Losses incurred or sustained by, or imposed upon, Seller Indemnitees based upon, arising out of, with respect to or by reason of:

(a)

any inaccuracy in or breach of any of the representations or warranties of Buyer contained in this Agreement or any other Transaction Document; and

(b)

any breach or non-fulfillment of any covenant, agreement or obligation to be performed by Buyer pursuant to this Agreement or any of the Transaction Documents.

Section 7.7

Cumulative Remedies.

(a)

The rights and remedies provided in this ARTICLE VII (and ARTICLE VI) are cumulative and are in addition to and not in substitution for any other rights and remedies available at Law or in equity or otherwise.

(b)

Notwithstanding anything to the contrary in this Agreement or any other Transaction Document, and without prejudice to any other right or remedy Buyer has or may have (whether under this Agreement, any other Transaction Document, at law, in equity or otherwise), if Buyer is entitled to indemnification or any other amount under this Agreement, Buyer, in its sole discretion, may elect to recover such indemnification or other such amount by (i) seeking cash directly from Seller and/or Guarantor hereunder, (ii) setting off such amount against any Liability that Buyer owes to Seller, any Affiliate of Seller or any third party under this Agreement, the Real Estate Purchase Agreement or Construction Management Services Agreement, regardless of whether either Liability is matured or unmatured, liquidated or unliquidated, or (iii) setting off such amount against any of the Contingent Payments.

ARTICLE VIII
POST-CLOSING COVENANTS AND OTHER AGREEMENTS

Section 8.1

Further Assurances.

(a)

From and after the Closing Date, each of the Parties hereto shall cooperate with one another and their respective affiliates, and shall execute and deliver such additional documents, instruments, conveyances and assurances and take such further actions as may be reasonably required to carry out the provisions of this Agreement and the other Transaction Agreements, and give effect to the transactions contemplated hereby and thereby. If any consent, approval, permit, license, or waiver of any third party necessary in connection with the transactions contemplated by this Agreement (including the execution of any other Transaction Agreements) has not been obtained by the applicable Party prior to date hereof, then such Party will cooperate and make all commercially reasonable efforts to obtain such consent or waiver as soon as practicable following the date hereof.

(b)

Without limiting the foregoing, the Seller shall deliver to the Buyer within two (2) Business Days of the Closing Date (or such later date as may be agreed to by the Buyer in its sole discretion), the following items:

(i)

the corporate record book of the Company, including true and complete copies of the Organizational Documents of the Company, including any amendments or restatements thereof;

(ii)

written resignations for all managers, officers and directors or other persons serving as a managerial official of the Company, effective as of the Closing, in form acceptable to the Buyer.

Section 8.2

Confidentiality.

(a)

Buyer is an Affiliate of a corporation listed on NASDAQ and subject to various rules and laws relating to disclosure. Neither Seller, nor any of its respective Affiliates, shall make any public announcement regarding this Agreement or the terms and conditions hereof or transactions contemplated hereby without prior written approval of Buyer. Nothing in this section prevents Buyer from making any discretionary press release nor Securities Exchange Commission filing in any form it believes is required by applicable Law.

(b)

Seller acknowledges and agrees that the protection of the Confidential Information relating to the Company and its assets and business is necessary to protect and preserve the value of the Company. Therefore, Seller hereby agrees for a period of three (3) years after the Closing not to disclose to any unauthorized individual or entity or use for their own account or for the benefit of any third party any Confidential Information, whether or not such information is embodied in writing or other physical form, unless and to the extent that the Confidential Information loses its status as Confidential Information other than as a result of the fault of Seller or the fault of any other individual or entity bound by a duty of confidentiality to Buyer or Seller. Seller agrees to deliver to Buyer at the Closing, and at any other time Buyer may request, all electronic files, documents and other materials that contain any Confidential Information and any other Confidential Information that Seller may then possess or have under its control. Upon Buyer’s request, Seller will permanently delete or destroy, and/or confirm the permanent deletion or destruction of, any Confidential Information, except that Seller may retain

a copy of Confidential Information solely as necessary for archival purposes to establish its rights and obligations under this Agreement or to investigate and defend any claims arising under it.

ARTICLE IX

GENERAL TERMS

Section 9.1

Expenses. Except as otherwise expressly provided herein, all Transaction Fees shall be paid by the Party incurring such costs and expenses, whether or not the Closing shall have occurred.

Section 9.2

Notices. All notices, requests, consents, claims, demands, waivers and other communications hereunder shall be in writing and shall be deemed to have been given (a) when delivered by hand (with written confirmation of receipt); (b) when received by the addressee if sent by a nationally recognized overnight courier (receipt requested); (c) on the date sent by facsimile or e-mail of a PDF document (with confirmation of transmission) if sent during normal business hours of the recipient, and on the next Business Day if sent after normal business hours of the recipient; or (d) on the 3rd day after the date mailed, by certified or registered mail, return receipt requested, postage prepaid. Such communications must be sent to the respective Parties at the following addresses (or at such other address for a Party as shall be specified in a notice given in accordance with Section 11.2):

If to Buyer:

CleanSpark, Inc.
10624 S Eastern Ave Ste A-638
Henderson, NV 89052
Attn: Leighton Koehler, General Counsel
Email: lkoehler@cleanspark.com

With a copy to (which shall not constitute notice):

Cozen O’Connor
1650 Market Street, Suite 2800
Philadelphia, Pennsylvania 19103
Attn: Joseph C. Bedwick
Email: jbedwick@cozen.com

    If to Seller:

    MakerStar Capital Inc. 
4 Park Plaza, Ste 1230
Irvine, CA 92614
Attention: Alex Wang 
Email: alex@makerstarcapital.com
 

   

Section 9.3

Interpretation. For purposes of this Agreement the words: (a) “include,” “includes” and “including” shall be deemed to be followed by the words “without limitation”; (b) “or” is not exclusive; and (c) “herein,” “hereof,” “hereby,” “hereto” and “hereunder” refer to this

Agreement as a whole. Unless the context otherwise requires, references herein to: (x) Articles, Sections, Disclosure Schedules and Exhibits mean the Articles and Sections of, and Disclosure Schedules and Exhibits attached to, this Agreement; (y) an agreement, instrument or other document means such agreement, instrument or other document as amended, supplemented and modified from time to time to the extent permitted by the provisions thereof and (z) a statute means such statute as amended from time to time and includes any successor legislation thereto and any regulations promulgated thereunder. The Disclosure Schedules and Exhibits referred to herein shall be construed with, and as an integral part of, this Agreement to the same extent as if they were set forth herein.

Section 9.4

JOINT EFFORTS; ACCESS TO COUNSEL. THE PARTIES EXPRESSLY ACKNOWLEDGE AND AGREE THAT THIS AGREEMENT IS THE RESULT OF JOINT EFFORTS OF BUYER AND SELLER AND EACH PROVISION HAS BEEN SUBJECT TO THE MUTUAL NEGOTIATION AND AGREEMENT OF THE BUYER AND SELLER AS EACH SUCH PARTY HAS DEEMED APPROPRIATE AND THAT THIS AGREEMENT HAS BEEN DRAFTED BY COUNSEL FOR THE BUYER AS A CONVENIENCE TO THE PARTIES ONLY. THE SELLER EXPRESSLY REPRESENTS AND WARRANTS THAT IT HAS READ, KNOWS, UNDERSTANDS AND AGREES WITH THE TERMS AND CONDITIONS OF THIS AGREEMENT AND THAT IT HAS HAD access to counsel of ITs choice to the extent IT DEEMED NECESSARY IN ORDER TO INTERPRET THE LEGAL EFFECT HEREOF. THE PARTIES ACKNOWLEDGE AND AGREE THAT THERE SHALL BE NO CONSTRUCTION AGAINST BUYER OR ANY OTHER PARTY BASED ON ANY PRESUMPTION OF THAT PARTY’S INVOLVEMENT IN THE DRAFTING OF THIS AGREEMENT.

Section 9.5

Headings. The headings in this Agreement are for reference only and shall not affect the interpretation of this Agreement.

Section 9.6

Severability. If any one or more of the terms of this Agreement are deemed to be invalid or unenforceable by a court of law, the validity, enforceability, and legality of the remaining provisions of this Agreement will not in any way be affected or impaired thereby, provided that: (i) each Party receives the substantial benefit of its bargain with respect to the transaction contemplated hereby; and (ii) the ineffectiveness of such provision would not result in such a material change as to cause completion of the transactions contemplated hereby to be unreasonable for either Party hereto.

Section 9.7

Entire Agreement. This Agreement and the other Transaction Documents constitute the sole and entire agreement of the Parties to this Agreement with respect to the subject matter contained herein and therein, and supersede all prior and contemporaneous understandings and agreements, both written and oral, with respect to such subject matter. In the event of any inconsistency between the statements in the body of this Agreement and those in the other Transaction Documents, the Exhibits and Disclosure Schedules (other than an exception expressly set forth as such in the Disclosure Schedules), the statements in the body of this Agreement will control.

Section 9.8

Successors and Assigns. This Agreement shall be binding upon and shall inure to the benefit of the Parties hereto and their respective successors and permitted assigns.

Neither Party may assign its rights or obligations hereunder without the prior written consent of the other; which consent shall not be unreasonably withheld, delayed or conditioned.

Section 9.9

No Third-Party Beneficiaries. Except as provided in Article VII, this Agreement is for the sole benefit of the Parties hereto and their respective successors and permitted assigns and nothing herein, express or implied, is intended to or shall confer upon any other Person or entity any legal or equitable right, benefit or remedy of any nature whatsoever under or by reason of this Agreement.

Section 9.10

Amendment and Modification; Waiver. This Agreement may only be amended, modified or supplemented by an agreement in writing signed by each Party hereto. No waiver by any Party of any of the provisions hereof shall be effective unless explicitly set forth in writing and signed by the Party so waiving. No waiver by any Party shall operate or be construed as a waiver in respect of any failure, breach or default not expressly identified by such written waiver, whether of a similar or different character, and whether occurring before or after that waiver. No failure to exercise, or delay in exercising, any right, remedy, power or privilege arising from this Agreement shall operate or be construed as a waiver thereof; nor shall any single or partial exercise of any right, remedy, power or privilege hereunder preclude any other or further exercise thereof or the exercise of any other right, remedy, power or privilege.

Section 9.11

Governing Law; Submission to Jurisdiction; Waiver of Jury Trial.

(a)

This Agreement shall be governed by and construed in accordance with the internal laws of the State of Mississippi without giving effect to any choice or conflict of law provision or rule (whether of the State of Mississippi or any other jurisdiction).

(b)

ANY LEGAL SUIT, ACTION OR PROCEEDING ARISING OUT OF OR BASED UPON THIS AGREEMENT, THE OTHER TRANSACTION DOCUMENTS OR THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY SHALL BE INSTITUTED EXCLUSIVELY IN THE STATE COURTS LOCATED IN HINDS COUNTY MISSISSIPPI, OR, IF SUCH COURT SHALL NOT HAVE JURISDICTION, ANY FEDERAL COURT LOCATED IN OR CLOSEST TO HINDS COUNTY, MISSISSIPPI, AND EACH PARTY IRREVOCABLY SUBMITS TO THE EXCLUSIVE JURISDICTION OF SUCH COURTS IN ANY SUCH SUIT, ACTION OR PROCEEDING. SERVICE OF PROCESS, SUMMONS, NOTICE OR OTHER DOCUMENT BY MAIL TO SUCH PARTY’S ADDRESS SET FORTH HEREIN SHALL BE EFFECTIVE SERVICE OF PROCESS FOR ANY SUIT, ACTION OR OTHER PROCEEDING BROUGHT IN ANY SUCH COURT. THE PARTIES IRREVOCABLY AND UNCONDITIONALLY WAIVE ANY OBJECTION TO THE LAYING OF VENUE OF ANY SUIT, ACTION OR ANY PROCEEDING IN SUCH COURTS AND IRREVOCABLY WAIVE AND AGREE NOT TO PLEAD OR CLAIM IN ANY SUCH COURT THAT ANY SUCH SUIT, ACTION OR PROCEEDING BROUGHT IN ANY SUCH COURT HAS BEEN BROUGHT IN AN INCONVENIENT FORUM.

(c)

EACH PARTY ACKNOWLEDGES AND AGREES THAT ANY CONTROVERSY WHICH MAY ARISE UNDER THIS AGREEMENT OR THE OTHER TRANSACTION DOCUMENTS IS LIKELY TO INVOLVE COMPLICATED AND DIFFICULT ISSUES AND, THEREFORE, EACH SUCH PARTY IRREVOCABLY AND

UNCONDITIONALLY WAIVES ANY RIGHT IT MAY HAVE TO A TRIAL BY JURY IN RESPECT OF ANY LEGAL ACTION ARISING OUT OF OR RELATING TO THIS AGREEMENT, THE OTHER TRANSACTION DOCUMENTS OR THE TRANSACTIONS CONTEMPLATED HEREBY OR THEREBY. EACH PARTY TO THIS AGREEMENT CERTIFIES AND ACKNOWLEDGES THAT (A) NO REPRESENTATIVE OF ANY OTHER PARTY HAS REPRESENTED, EXPRESSLY OR OTHERWISE, THAT SUCH OTHER PARTY WOULD NOT SEEK TO ENFORCE THE FOREGOING WAIVER IN THE EVENT OF A LEGAL ACTION, (B) SUCH PARTY HAS CONSIDERED THE IMPLICATIONS OF THIS WAIVER, (C) SUCH PARTY MAKES THIS WAIVER VOLUNTARILY, AND (D) SUCH PARTY HAS BEEN INDUCED TO ENTER INTO THIS AGREEMENT BY, AMONG OTHER THINGS, THE MUTUAL WAIVERS AND CERTIFICATIONS IN THIS SECTION 9.10(c).

(d)

The Parties agree that irreparable damage would occur in the event that any of the provisions of this Agreement were not performed in accordance with their specific terms or were otherwise breached. Accordingly, the Parties agree that, in addition to any other remedies, each Party shall be entitled to enforce the terms of this Agreement by a decree of specific performance without the necessity of proving the inadequacy of money damages as a remedy. Each Party hereby waives the requirement for the securing or posting of any bond in connection with such remedy.

Section 9.12

Attorneys’ Fees. If any action at law or in equity is necessary to enforce or interpret the terms of this Agreement or any of the other Transaction Documents, the prevailing party shall be entitled to reasonable attorneys’ fees, costs and necessary disbursements in addition to the any other relief to which such Party may be entitled.

Section 9.13

Counterparts. This Agreement may be executed in counterparts, each of which shall be deemed an original, but all of which together shall be deemed to be one and the same agreement. A signed copy of this Agreement delivered by facsimile, e-mail or other means of electronic transmission shall be deemed to have the same legal effect as delivery of an original signed copy of this Agreement.

[Signatures contained on following page.]

IN WITNESS WHEREOF, the Parties hereto have caused this Agreement to be executed as of the date first written above.

BUYER:

CSRE PROPERTIES MISSISSIPPI, LLC

By: /s/ Zachary Bradford .

Name: Zachary Bradford

Title: Manager

SELLER:

Eyas Investment Group Limited

By: /s/ Shengyin Chen .

Name: Shengyin Chen

Title: CEO

Solely for purposes of Article VII:

MAKERSTAR CAPITAL, INC.

By: /s/ Shengyin Chen .

Name: Shengyin Chen

Title: CEO

REAL ESTATE PURCHASE AND SALE AGREEMENT

THIS REAL ESTATE PURCHASE AND SALE AGREEMENT (“Agreement”) is dated as of the 16th day of September, 2024 (“Effective Date”) by and between Makerstar Capital, Inc., a Delaware corporation (the “Seller”), and CSRE Properties Mississippi, LLC, a Mississippi limited liability company (the “Buyer”).

IN CONSIDERATION of the respective agreements hereinafter set forth, Seller and Buyer agree as follows:

Property Included in Sale. Seller hereby agrees to sell and convey to Buyer, and Buyer hereby agrees to purchase from Seller, subject to the terms and conditions set forth herein, the following:

(a)

Real Property. All that certain real property located in the City of Clinton, County of Hinds, State of Mississippi as forth on Exhibit A attached hereto and as more particularly described in Exhibit B attached hereto (the “Real Property”);

(b)

Improvements. All improvements and fixtures located on the Real Property, including the building(s) and any other structures presently located on the Real Property, and all apparatus, equipment and appliances owned by Seller and used in connection with the ownership, use, operation or occupancy of the Real Property (collectively, the “Improvements”); and

(c)

Personal Property. All machinery, equipment, appliances, furniture, furnishings and other personal property owned by Seller and located on or in, affixed to or used in connection with the Real Property and Improvements (the “Personal Property”).

All of the items referred to in Sections 1(a) - (c) above are hereinafter collectively referred to as the “Property”.

Purchase Price.

(a)

Purchase Price. The total purchase price for the Property is Seven Hundred Thousand and 00/100 Dollars ($700,000.00) (the “Purchase Price”), allocated as follows:

Frontage Road property: Six Hundred Fifty Thousand and 00/100 Dollars ($568,750.00).

Industrial Park Drive property: One Hundred Fifty Thousand and 00/100 Dollars ($131,250.00).

The Purchase Price shall be paid by wire transfer of immediately available federal funds at Closing (as defined in Section 5(a) herein).

Due Diligence.

(a)

Diligence Period. Buyer shall have a period of time beginning on the Effective Date and continuing until the Closing Date (the “Diligence Period”) to conduct Inspections, review the Due Diligence Items, and confirm the condition of title to the Property.

(b)

Inspections. During the Diligence Period, Buyer shall have the right to enter upon the Property for the purposes of surveying, staking, engineering, conducting soil tests, and conducting such other inspections, tests, reports, and studies as Buyer shall deem appropriate or desirable in Buyer’s sole and absolute discretion including, without limitation, (i) Phase I environmental studies and assessments and, if recommended by the Phase I, Phase II environmental studies and assessments, and (ii) verifications of zoning and code compliance (collectively, the “Inspections”). Seller shall permit and, to the extent reasonably required by Buyer, shall assist Buyer in providing access to Seller’s engineers, contractors, subcontractors, managers, and analysts in connection with Buyer’s Inspections.

(c)

Costs of; Prohibitions on Liens. All costs and expenses of Buyer’s Inspections shall be paid by Buyer when due, regardless of whether Closing occurs. Buyer shall not permit any mechanics’ or materialmen’s liens or any other liens to attach to the Property by reason of the performance of any work or the purchase of any materials by Buyer or any other party in connection with any inspections conducted by or for Buyer.

(d)

Indemnity. Buyer shall hold Seller harmless from, and indemnify Seller against, all cost, damage, expense, liability, lien, or claim which is caused by any act or omission of Buyer or any agent or employee of Buyer during the course of Buyer’s Inspections. Notwithstanding the preceding, Buyer shall have no liability for, or obligation to remedy, indemnify, or otherwise take any action: (a) to the extent Buyer’s inspections or tests discover or reveal pre-existing conditions, defects, liabilities, or claims in or to Seller’s title to the Property, or the physical or environmental condition of the Property, (b) by reason of Buyer fulfilling any mandatory reporting obligation placed upon Buyer by applicable law because of the information discovered or revealed during the Diligence Period, or (c) which arise from Seller’s gross negligence or willful misconduct. If Closing does not occur, then this Section 3(d) shall survive the expiration or earlier termination of this Agreement.

(e)

Title and Survey. Buyer has obtained (the “Title Commitments”) issued by the Title Company (as defined below). Buyer may, at Buyer’s sole cost and expense, obtain new surveys (the “Surveys”) of the Property to be prepared in accordance with Buyer’s requirements. No later than five (5) days prior to the expiration of the Diligence Period, Buyer shall provide written notice to Seller (the “Title Notice”) of any material exceptions or conditions related to title contained in the Title Commitments or Surveys (the “Title Matters”) which are unacceptable to Buyer,

in Buyer’s sole and absolute discretion, and which cure action(s) thereon will be acceptable to Buyer, in Buyer’s sole and absolute discretion (the “Title Objections”). If Buyer fails to timely provide the Title Notice, then Buyer shall be deemed to have waived its right to object hereunder and to have accepted all matters related to title contained in the Title Commitments or Surveys. Although Seller may elect, in Seller’s sole and absolute discretion, to cure or attempt to cure any one or more Title Objections, Buyer acknowledges and agrees that Seller has no obligation to cure any Title Objections, save and except each Monetary Lien (as defined below), which shall be released and removed from the Property at Closing. Seller shall, within five (5) days following receipt of the Title Notice, provide written notice (the “Seller’s Title Notice”) to Buyer stating whether Seller elects to cure any of the Title Objections in the manner required by Buyer in the Title Notice; provided that if Seller fails to provide Seller’s Title Notice, then Seller shall be deemed to have elected not to cure any of the Title Objections. If Seller elects to cure less than all of the Title Objections in the manner required by Buyer in the Title Notice (or are deemed to have elected not to cure), then Buyer shall have the right to: (a) terminate this Agreement as to any or all of the parcels comprising the Property by written notice to Seller (the “Title Termination Notice”) given prior to the expiration of the Diligence Period, in which event this Agreement shall terminate, and neither party shall owe any further obligation or liability to the other party under this Agreement, except for those obligations and liabilities which expressly survive the termination hereof, or (b) proceed to Closing and accept the respective Property, subject to the Permitted Exceptions (as defined below), without a reduction of the Purchase Price. Buyer’s failure to serve a Title Termination Notice shall be deemed Buyer’s election to accept the conveyance under clause (b) above. All Title Objections that Seller agreed to cure shall be cured by Seller prior to the Closing in the manner required by Buyer in the Title Notice. Seller’s failure to timely cure shall constitute a default pursuant to Section 11(b) herein. All Title Matters set forth in the Title Commitments and the Surveys to which Buyer does not object in the Title Notice, and all Title Objections as to which Buyer has waived its objection as set forth above are referred to collectively as the “Permitted Exceptions.” The amount necessary to discharge each Monetary Lien and any other Title Objections that Seller agreed to cure may be paid out of the proceeds of the monies otherwise payable to Seller at the Closing. Notwithstanding anything to the contrary set forth herein, Seller shall be obligated to satisfy and remove as exceptions to title, at Closing, any security instruments, mortgages, deeds of trust, monetary lien, judgments, or other matters that can be removed by the payment of money (each a “Monetary Lien”) encumbering the Property or any part thereof, and any lien or encumbrance that attached to the Property from and after the Effective Date which was not caused by the actions of Buyer or any party claiming by, through or under Buyer. Should any update of the Title Commitments or Surveys received between the expiration of the Diligence Period and Closing reveal any new title exceptions, Buyer shall be entitled to the same process outlined hereinabove for its original title review and objections.

(f)

Buyer’s Diligence Termination Right. If the Property is not satisfactory to Buyer, in Buyer’s sole and absolute discretion, for any reason or no reason, whether related

or unrelated to the Inspections or Title Matters, then Buyer may, by written notice to Seller given on or before the expiration of the Diligence Period, terminate this Agreement as to any or all of the parcels comprising the Property by written notice to Seller (the “Diligence Termination Notice”), following which neither Party shall owe any further obligation or liability to the other Party under this Agreement, except for those obligations and liabilities which expressly survive the termination hereof. If Buyer fails to timely deliver a Diligence Termination Notice as to any or all of the parcels comprising the Property, then Buyer shall be deemed to have elected to proceed to Closing in relation to the respective Property. For the avoidance of doubt, the termination right afforded to Buyer pursuant to Section 3(e) is separate, apart, and additional to the termination right afforded to Buyer under this Section 3(f).

Conditions to Closing.

(a)

Buyer’s Conditions. The following are conditions precedent to Buyer’s obligation to purchase the Property:

(i)

MIPA. Seller, Buyer, and Eyas Investment Group Limited, formerly known as Coinmaker Miners Limited (the “MIPA Seller”), have executed and delivered that certain Membership Interest Purchase Agreement of even date herewith, attached hereto as Exhibit E (the “MIPA”).

(ii)

Electric Service Contracts. Seller has caused its interest in the following contracts to be assigned to the Company, or an affiliate thereof as designated by CleanSpark, Inc. (as defined in the MIPA) simultaneously with the Closing:

Agreement for Electrical Service dated April 30, 2024 between MakerStar Capital, Inc. and Entergy in relation to the Frontage Road, Clinton, MS property; and

Agreement for Electrical Service dated April 30, 2024 between MakerStar Capital, Inc. and Entergy in relation to the Industrial Park Drive, Clinton, MS property.

(iii)

Title. Title to the Real Property shall be good and marketable, and insurable as such pursuant to the standard stipulations and conditions of the most current form of ALTA Policy of Title Insurance in use in the State of Mississippi (the policies issued to Buyer pursuant to the Closing shall be referred to as the “Title Policies”). Notwithstanding anything contained in this Agreement, Seller shall cause to be paid, discharged and released at Closing: (i) all mortgages, deeds of trust, and deeds to secure debt or other monetary lien voluntarily granted or expressly assumed by Seller and encumbering the Real Property; (ii) all past due real estate taxes and assessments which constitute a lien against the Real Property; (iii) all mechanic’s liens encumbering the Real Property; and (iv) all other liens,

judgments, or encumbrances that may be satisfied by the payment of money. Seller shall obtain all certificates, approvals, and other instruments, if any, required by applicable laws to permit title to the Real Property to be lawfully transferred to Buyer. Seller shall neither place nor consent to any Title Matters attaching, encumbering, or otherwise affecting the Property from and after the Effective Date, or amend, terminate, or renew any instruments memorialize any Title Matters which exist on the Effective Date, without in each case the prior written consent of Buyer, which consent may be withheld, conditioned, or delayed in Buyer’s sole and absolute discretion. Should Seller suffer the attachment, encumbrance, modification, or alteration of any Title Matters from and after the Effective Date, then Seller shall, promptly following Seller’s notice thereof, provide Buyer with notice and documentation thereof.

(iv)

Accuracy of Seller’s Representations and Warranties. All of Seller’s representations and warranties contained in or made pursuant to this Agreement shall be true and correct in all material respects as of the Closing Date.

(v)

No Seller Breach. There shall be no material breach of Seller’s covenants and obligations set forth in this Agreement.

(vi)

Seller’s Deliveries. Seller shall have delivered the items described in Section 5(b) to Buyer or to the Title Company (as defined in Section 5(a)).

(vii)

Title Insurance. As of the Closing, the Title Company will issue or have committed to issue the Title Policies to Buyer.

(viii)

NASDAQ Approval. On or before the Closing Date, any prior approvals required by NASDAQ rules or applicable law that pertain to Buyer as an affiliate of a listing corporation shall have been obtained in writing, without qualification or condition.

(ix)

Governmental Approvals. On or before the Closing Date, any federal, state, or local governmental approvals (including any zoning approval) required for the operation of a bitcoin mining operation at the Property shall have been obtained in writing, without qualification or condition.

(x)

Contract for Electric Service. On or before the Closing Date, Buyer, or an affiliate thereof, shall enter into a contract for the provision of electric power to the Property in a capacity that is adequate (in Buyer’s sole discretion) for Buyer’s intended use of bitcoin mining, and otherwise is on commercially reasonable terms, in Buyer’s reasonable opinion.

Buyer covenants to use good faith efforts to obtain the approvals, if any, required by paragraphs (viii), (ix) and (x) above, prior to Closing. The Closing pursuant to this Agreement shall be deemed a waiver by Buyer of all unfulfilled conditions hereunder benefiting Buyer.

(b)

Seller’s Conditions. It shall be a condition precedent to Seller’s obligation to sell the Property that all of Buyer’s representations and warranties contained in or made pursuant to this Agreement shall be true and correct in all material respects as of the Closing Date, that there shall be no material breach of Buyer’s covenants and obligations set forth in this Agreement, and that Buyer shall have delivered the items described in Section 5(c) to Seller or to Title Company. The Closing pursuant to this Agreement shall be deemed a waiver by Seller of all unfulfilled conditions hereunder benefiting Seller.

(c)

Benefit of Conditions. The conditions set forth in Sections 4(a) are for the exclusive benefit of Buyer and the conditions set forth in Section 4(b) are for the exclusive benefit of Seller.

Closing and Escrow.

(a)

Closing. The closing of the purchase and sale contemplated by this Agreement (the “Closing”) shall occur within forty-five (45) days of the closing of the transactions contemplated under the MIPA (the “Closing Date”). Buyer, in its sole discretion, may accelerate the Closing Date to a date of its choice upon at least five (5) days’ prior notice to Seller. The Closing shall take place by correspondence at the office of Land Services USA, LLC (the “Title Company”), or through escrow with Title Company serving as the escrow agent. Seller agrees to deliver possession of the Property to Buyer on the Closing Date.

(b)

Seller’s Deliveries. At or before the Closing, Seller shall deliver to Buyer the following:

(i)

the duly executed and acknowledged MIPA in the form attached hereto as Exhibit E;

(ii)

duly executed and acknowledged Warranty Deeds, in the forms attached hereto as Exhibit C-1 and C-2, conveying to the Buyer the Real Property and the Improvements;

(iii)

a duly executed Warranty Bill of Sale for the Personal Property, in the form attached hereto as Exhibit D;

(iv)

counterparts of any required transfer tax returns, or in each instance and if available, an electronic filing of such returns, together with the required payment of applicable transfer taxes, pursuant to the requirements of the State of Mississippi and local taxing authorities;

(v)

an affidavit pursuant to Section 1445(b)(2) of the Federal Code, and on which Buyer is entitled to rely, that Seller is not a “foreign person” within the meaning of Section 1445(f)(3) of the Federal Code;

(vi)

an Affidavit of Title from Seller in a form reasonably acceptable to the Title Company, sufficient to permit the Title Company to delete from the title

commitment for the Real Property the standard exceptions for mechanics’ liens, parties in possession, and unrecorded liens and encumbrances resulting from the actions of Seller prior to the Closing Date.

(vii)

a closing statement prepared by Title Company and approved in writing by Seller;

(viii)

such resolutions, authorizations, bylaws or other corporate and/or partnership documents or agreements relating to Seller as shall be reasonably required in connection with this transaction;

(ix)

a certificate of Seller, duly executed by Seller, confirming that all of the representations and warranties of Seller contained in Section 6(a) hereof are true and correct in all material respects as of the Closing Date; and

(x)

any other documents, instruments or records which are reasonably required by Title Company to close the escrow and consummate the purchase of the Property in accordance with the terms hereof.

(c)

Buyer Deliveries. At or before the Closing, Buyer shall deliver to Seller the following:

(i)

the duly executed and acknowledged MIPA in the form attached hereto as Exhibit E;

(ii)

cash or other immediately available funds in the amount of the Purchase Price;

(iii)

such resolutions, authorizations, bylaws or other corporate and/or partnership documents or agreements relating to Buyer as shall be reasonably required in connection with this transaction;

(iv)

a closing statement prepared by Title Company and approved in writing by Buyer; and

(v)

any other documents, instruments or records which are reasonably required by Title Company to close the escrow and consummate the purchase of the Property in accordance with the terms hereof.

(d)

Prorations. Real property taxes and assessments, water, sewer and utility charges, annual permits and/or inspection fees (calculated on the basis of the period covered), and other expenses normal to the operation and maintenance of the Property, shall be prorated as of 12:01 a.m. on the Closing Date on the basis of a 365-day year. Buyer hereby agrees that if any of therefore said prorations described in this Section 5(d) cannot be calculated accurately on the Closing Date, then the same shall be calculated within sixty (60) days after the end of the calendar year in which the Closing occurs, and either party owing the other party a sum of money

based on such subsequent proration (s) shall promptly pay said sum to the other party. This Section 5(d) shall survive Closing.

(e)

Closing Costs and Adjustments. Seller shall pay the cost of any documentary stamp taxes, transfer taxes, or similar taxes applicable to the sale of the Property. Buyer shall pay the premium for the Title Policies, including premiums for any extended coverage policy of title insurance, inspection and survey costs, and the cost of any endorsements to the Title Policies. Recording fees and all other costs and charges of the escrow for the sale shall be paid in the manner customary for the county in which the Property is located or, if there is no custom, shall be split equally between Buyer and Seller.

(f)

Utilities. Seller shall cooperate with Buyer to transfer all utilities for the Property to Buyer’s name as of the Closing Date. Seller shall be entitled to recover any and all deposits with respect to the Property held by any utility company as of the Closing Date or, if any such deposit is assignable and Seller so assigns them to Buyer, then the amount of such deposits shall be credited to Seller at Closing and the Purchase Price shall be adjusted accordingly.

(g)

Possession. Possession of the Property shall be delivered to Buyer on the Closing Date, free and clear of all tenancies.

Representations and Warranties.

(a)

Seller’s Representations and Warranties. Seller hereby represents and warrants to Buyer that as of the date of this Agreement and as of the date of the Closing:

(i)

No other person or entity has a contract or option to purchase, letter of intent, right of first refusal or first offer, or similar rights with respect to the Property that is now outstanding.

(ii)

Seller has the right to transfer fee simple ownership to the Property to Buyer.

(iii)

To Seller’s knowledge, Seller has received no notice from any governmental authority with jurisdiction over the Property of any current violation by the Property of any laws or regulations applicable to the Property. Seller shall immediately provide Buyer with a copy of any such notices received after the Effective Date.

(iv)

There are no leases, licenses, or agreements for occupancy currently in effect with respect to all or any portion of the Property.

(v)

There are no contracts or agreements relating to the ownership, operation and maintenance of the Property that will survive the Closing.

(vi)

There is no litigation pending or threatened against Seller that arises out of Seller’s ownership or operation of the Property.

(vii)

To Seller’s knowledge, no condemnation or eminent domain proceedings are pending or threatened against the Property.

(viii)

All documents delivered to Buyer pertaining to the Property (the “Due Diligence Items”) are true and complete copies of the same documents (originals or copies) that are in Seller’s possession and used in connection with the operation and management of the Property. None of the Due Diligence Items have been amended, modified or terminated except as disclosed in writing to Buyer.

(ix)

Seller has received no notice of any violation of Environmental Laws or the presence or release of Hazardous Materials (as defined below) on or from the Property in violation of Environmental Laws except as may be disclosed in any environmental reports or assessments included in the Due Diligence Items. The term “Environmental Laws” means the Resource Conservation and Recovery Act and the Comprehensive Environmental Response Compensation and Liability Act and other federal laws governing the environment as in effect on the date of this Agreement, together with their implementing regulations, guidelines, rules or orders as of the date of this Agreement, and all state, regional, county, municipal and other local laws, regulations, ordinances, rules or orders that are equivalent or similar to the federal laws recited above or that purport to regulate Hazardous Materials.

(x)

To Seller’s knowledge, there are no structural or other defects in the Improvements, and the building systems at or servicing the Improvements or the Property are in good condition and working order.

(xi)

This Agreement and all documents executed by Seller which are to be delivered to Buyer at the Closing are or at the time of Closing will be duly authorized, executed, and delivered by Seller, and are or at the time of Closing will be legal, valid, and binding obligations of Seller.

(xii)

Seller is a corporation organized, validly existing and in good standing under the laws of Delaware with full power to enter into this Agreement, and Seller is duly qualified to transact business in Mississippi. This Agreement and all other documents executed by Seller and delivered to Buyer prior to or at the Closing (i) have been, or will be when delivered, duly authorized, executed and delivered by Seller; (ii) are binding obligations of Seller; (iii) do

not violate the provisions of any agreement to which Seller is party or which affects the Property.

(xiii)

Seller (a) is not acting, directly or indirectly, for or on behalf of any person, group, entity or nation named by any Executive Order or the United States Department of the Treasury as a terrorist, “Specially Designated and Blocked Persons”, or other banned or blocked person, group, entity, nation or transaction pursuant to any law, order, rule, or regulation that is enforced or administered by the Office of Foreign Asset Control (“OFAC”) of the United States Department of the Treasury; and (b) is not engaged, directly or indirectly, in any dealings or transactions and is not otherwise associated with such person, group, entity or nation.

For purposes of this Agreement, whenever the phrase “to Seller’s knowledge” is used, it shall refer to the actual knowledge of Shengyin Chen, Alex Wang, and the officers of Makerstar Capital, Inc., for the Property, after reasonable and diligent inquiry and investigation.

(b)

Representations and Warranties of Buyer. Buyer hereby represents and warrants to Seller that as of the date of this Agreement and as of the Closing Date:

(i)

Buyer is a limited liability company, duly organized and validly existing under the laws of the State of Mississippi and is qualified to do business and in good standing under the laws of the State of Mississippi; this Agreement and all documents executed by Buyer which are to be delivered to Seller at the Closing are or at the time of Closing will be duly authorized, executed, and delivered by Buyer, and are or at the Closing will be legal, valid, and binding obligations of Buyer, and do not and at the time of Closing will not violate any provisions of any agreement or judicial order to which Buyer is a party or to which it is subject.

(ii)

Buyer (a) is not acting, directly or indirectly, for or on behalf of any person, group, entity or nation named by any Executive Order or the United States Department of the Treasury as a terrorist, “Specially Designated and Blocked Persons”, or other banned or blocked person, group, entity, nation or transaction pursuant to any law, order, rule, or regulation that is enforced or administered by OFAC; and (b) is not engaged, directly or indirectly, in any dealings or transactions and is not otherwise associated with such person, group, entity or nation.

Indemnification.

(a)

Seller Indemnification. Seller shall indemnify, protect, defend and hold harmless Buyer from any claim, loss, damage, cost or expense, including all reasonable attorneys’ fees, asserted against or suffered by Buyer resulting from (i) third party claims that arise due to Seller’s breach prior to Closing of an agreement entered into by Seller or its agents with respect to the Property, (ii) third party claims for personal injury or property damage that arise from events that occurred on the Property prior to Closing, and (iii) any breach of Seller’s representations and warranties contained in this Agreement. Notwithstanding anything to the contrary in this Agreement, and without prejudice to any other right or remedy Buyer has or may have at law, in equity or otherwise), if Buyer is entitled to indemnification or any other amount under this Agreement, Buyer, in its sole discretion, may elect to recover such indemnification or other such amount by seeking cash directly from Seller hereunder or by setting off such amount against any liability that Buyer owes to Seller or any affiliate of Seller under that Construction Management Services Agreement by and between Seller and/or Beast Power, Inc. and CSRE Properties Mississippi, LLC regardless of whether either liability is matured or unmatured, liquidated or unliquidated

(b)

Buyer Indemnification. Buyer shall indemnify, protect, defend and hold harmless Seller from any claim, loss, damage, cost or expense, including all reasonable attorneys’ fees, asserted against or suffered by Seller resulting from (i) third party claims that arise due to Buyer’s breach after Closing of an agreement entered into or expressly assumed by Buyer or its agents with respect to the Property, (ii) third party claims for personal injury or property damage that arise from events that occur on the Property after Closing, and (iii) any breach of Buyer’s representations and warranties contained in this Agreement.

(c)

Continuation and Survival. The indemnification provisions of this Section 7 and all representations and warranties by the respective parties contained herein or made in writing pursuant to this Agreement shall survive the execution and delivery of this Agreement and the delivery of the deeds and transfer of title, provided that the non-representing party must give the representing party written notice of any claim it may have against the representing party for a breach of any such representation or warranty within twelve (12) months after the Closing Date (the “Survival Period”). Any claim which either party may have at any time, whether known or unknown, which is not asserted within the Survival Period shall not be valid or effective, and the representing party shall have no liability with respect thereto.

Seller’s Disclaimer; Condition of the Property.

(a)

Seller Disclosures and Buyer Acknowledgement. Buyer acknowledges the following:

(i)

Other than those specifically set forth in this Agreement, Seller is not making and has not at any time made any warranty or representation of any kind, expressed or implied, with respect to the Property, including, without limitation, warranties or

representations as to habitability, merchantability, fitness for a particular purpose, title, zoning, tax consequences, latent or patent physical or environmental condition, utilities, operating history or projections, valuation, projections, or compliance with law.

(ii)

Other than those specifically set forth in this Agreement, Buyer is not relying upon and is not entitled to rely upon any representations and warranties made by Seller or anyone acting or claiming to act on Seller’s behalf.

(b)

“AS-IS. WHERE-IS AND WITH ALL FAULTS”. BASED UPON BUYER’S FAMILIARITY WITH, AND DUE DILIGENCE RELATING TO, THE PROPERTY, AND IN DIRECT CONSIDERATION OF SELLER’S DECISION TO SELL THE PROPERTY TO BUYER FOR THE PURCHASE PRICE, BUYER SHALL PURCHASE THE PROPERTY IN AN “AS IS, WHERE IS AND WITH ALL FAULTS” CONDITION ON THE CLOSING DATE AND ASSUMES FULLY THE RISK THAT ADVERSE LATENT OR PATENT PHYSICAL, ENVIRONMENTAL, ECONOMIC OR LEGAL CONDITIONS MAY NOT HAVE BEEN REVEALED BY ITS INVESTIGATIONS, SUBJECT ONLY TO SELLER’S EXPRESS REPRESENTATIONS AND WARRANTIES CONTAINED IN THIS AGREEMENT OR THE DUE DILIGENCE ITEMS. SELLER AND BUYER ACKNOWLEDGE THAT THE COMPENSATION TO BE PAID TO SELLER FOR THE PROPERTY HAS TAKEN INTO ACCOUNT THAT THE PROPERTY IS BEING SOLD SUBJECT TO THE PROVISIONS OF THIS SECTION 8. IF SELLER BREACHES ANY REPRESENTATION, WARRANTY, OR COVENANT HEREUNDER PRIOR TO CLOSING AND BUYER CLOSES ESCROW WITH ACTUAL KNOWLEDGE THEREOF. BUYER SHALL BE DEEMED TO WAIVE SUCH BREACH. THE CLOSING SHALL CONSTITUTE A REAFFIRMATION BY BUYER AND SELLER OF EACH OF THE PROVISIONS OF THIS SECTION 8 AND EACH OF THEM SHALL BE CONTINUING IN NATURE AND SHALL SURVIVE THE CLOSING. “ACTUAL KNOWLEDGE” OF BUYER FOR PURPOSES OF THIS SECTION SHALL REFER TO THE ACTUAL KNOWLEDGE OF ALEX WANG AND SHENGYIN CHEN, WITHOUT SUCH PERSON UNDERTAKING ANY INVESTIGATION OTHER THAN IN THE ORDINARY COURSE OF ITS RESPONSIBILITIES IN CONNECTION WITH THE ACQUISITION OF THE PROPERTY.

Seller Guaranty of MIPA.

(a)

Grant of Guaranty.

(i)

To induce Buyer to enter into the MIPA, Seller absolutely, unconditionally, and irrevocably guarantees to Buyer, as primary obligor and not merely as surety, the full and punctual payment when due and performance of all (i) obligations, covenants, and

agreements (including all reimbursement or indemnification obligations that may arise pursuant to Article VII of the MIPA and all costs, expenses, and fees associated or incurred by MIPA Seller in connection therewith) now or hereafter existing under or in respect of the MIPA of every kind and description, direct or indirect, secured or unsecured, joint or several, absolute or contingent (the “Guaranteed Obligations”), and agrees to pay any and all costs and expenses (including fees and expenses of counsel) incurred by the MIPA Seller in enforcing any rights under this guaranty, the MIPA or any other Transaction Document (as defined under the MIPA). Without limiting the generality of the foregoing, Seller’s liability shall extend to all amounts that constitute part of the Guaranteed Obligations and would be owed by the MIPA Seller to the Buyer under or in respect of the Transaction Documents (as defined under the MIPA) but for the fact that they are unenforceable or not allowable due to the existence of a bankruptcy, reorganization or similar proceeding involving the MIPA Seller. It is the intent of Seller that this guaranty shall be a guaranty of payment and not a guaranty of collection.

(ii)

This guaranty includes, but is not limited to, obligations arising under successive transactions continuing, compromising, extending, increasing, modifying, releasing, or renewing obligations, payment terms, or other terms and conditions thereof, or creating new or additional obligations after prior obligations have been satisfied in whole or in part. To the maximum extent permitted by law, Seller hereby waives and agrees not to assert any right Seller has under governing law, or otherwise, to revoke this guaranty as to future obligations.

(iii)

Seller agrees that Buyer may in its absolute discretion and without prejudice to or in any way limiting Seller’s liability for the Guaranteed Obligations: (a) extend credit to MIPA Seller, in such amounts and at such times as Buyer may determine, and whether Seller has any knowledge of facts with respect to MIPA Seller which might be construed as materially prejudicial to the interests of Seller, Buyer being hereby relieved of any duty to disclose any such facts to Seller; (b) grant extensions of time or other indulgences; (c) charge interest; (d) modify, exchange, renew, enforce or abstain from perfecting any security; (e) accept or make compositions or other arrangements or file or refrain from filing a claim in any bankruptcy proceeding of MIPA Seller; (f) discharge or release any party; (g) realize on any security; and (h) otherwise deal with MIPA Seller or any other party and the security as Buyer may deem expedient.

(b)

Guaranty of Payment Absolute and Unconditional; Waivers. This guaranty is a guaranty of payment and is absolute. Seller agrees that Seller’s liability hereunder shall be immediate and the Buyer need not attempt to collect any obligations from the MIPA Seller or any other Person or to realize upon any collateral to enforce the obligations hereunder. Seller guarantees that the Guaranteed Obligations will be paid strictly in accordance with the terms of this guaranty and the MIPA, regardless of any law, regulation, or order now or hereafter in effect in any jurisdiction affecting any of such terms or the rights of the Buyer with respect thereto. The obligations of Seller under this guaranty are independent of the obligation MIPA Seller, and a separate action or actions may be brought and prosecuted against the MIPA Seller or any other guarantors, or the MIPA Seller or any other guarantor may be joined in any such action or actions. The liability of Seller under this guaranty constitutes a primary obligation and not a contract of surety, and to the extent permitted by law, shall be irrevocable, continuing, absolute, and unconditional.

Seller hereby irrevocably waives, to the fullest extent permitted by applicable law, any defenses it may now or hereafter have in any way relating to any or all of the following:

(i)

Any lack of validity or enforceability of the Guaranteed Obligations or any agreement or instrument relating thereto.

(ii)

Any change in the time, manner, or place of payment of, or in any other term of any of the Guaranteed Obligations, or any other amendment or waiver of, or any consent to depart from, the agreements entered into by the parties, including, without limitation, any increase in the Guaranteed Obligations resulting from the extension of additional credit to the MIPA Seller or otherwise.

(iii)

Any taking, release, or amendment or waiver of or consent to departure from any other guaranty, for all or any of the Guaranteed Obligations.

(iv)

Promptness, diligence, notice of acceptance, and any other notice with respect to any of the Guaranteed Obligations and this guaranty, and any requirement that the Buyer exhausts any right or take any action against the MIPA Seller, any other person or entity or any collateral. Seller acknowledges that it will receive direct and indirect benefits from the arrangements contemplated herein and that the waiver set forth in this Section 9 is knowingly made in contemplation of such benefits.

(v)

Seller hereby unconditionally and irrevocably waives any right to revoke this guaranty and acknowledges that this guaranty is

continuing in nature and applies to all presently existing and future Guaranteed Obligations.

(vi)

Any other circumstance (including, without limitation, any statute of limitations) or manner of administering the Guaranteed Obligations or any existence of or reliance on any representation by the Buyer that might vary the risk of Seller or otherwise operate as a defense available to, or a legal or equitable discharge of, the MIPA Seller or any other guarantor or surety.

Seller acknowledges that it will receive substantial direct and indirect benefits from the transactions contemplated by the MIPA and that the waivers set forth in this guaranty are knowingly made in contemplation of such benefits. The obligations of Seller under this Section 9 are separate and independent of its obligations to convey the Property pursuant to the remainder of this Agreement, and shall survive the Closing and termination of this Agreement.

10.

Condemnation and Casualty.

(a)

Condemnation. If any authority having the right of eminent domain shall commence negotiations with Seller or shall commence legal action against Seller for the damaging, taking, or acquiring of all or a portion of any of the parcels comprising the Property, either temporarily or permanently, by condemnation or by exercise of the right of eminent domain, Seller shall immediately give notice of the same to Buyer. If the damaging, taking, or acquiring would affect all or a portion of any parcel of the Property that, according to Buyer’s good-faith estimate, would involve a portion valued at more ten percent (10%) of the allocated Purchase Price amount of the respective parcel set forth in Section 2(a) herein (the “Threshold Amount”), Buyer shall have the right, at its option, to terminate this Agreement, either in total or in relation to the affected parcel, by giving notice thereof to Seller on or before the date of Closing, in which event Buyer shall be released of all further respective obligations hereunder. If Buyer does not so terminate this Agreement or the taking does not involve a portion of the Property in excess of the Threshold Amount, the Purchase Price for the Property shall be reduced by the total of any awards, settlement proceeds, or other proceeds received by Seller prior to date of Closing with respect to any damaging, taking or acquiring. At Closing, Seller shall assign to Buyer all rights of Seller in and to any such awards, settlement proceeds, or other proceeds which are payable at or after the date of Closing. The risk of condemnation or eminent domain shall be borne by Seller until the date of Closing. In the event of any negotiations with any authority regarding the payment of any awards or other sums or regarding any settlement on account of any damaging, taking, or acquiring through condemnation or eminent domain, Seller will inform Buyer of all such negotiations of which Seller has notice and will permit Buyer to take part therein.

(b)

Casualty. Seller shall promptly give notice to Buyer of any damage by casualty to the Property as soon as reasonably practicable after the occurrence thereof. If the

Property suffers any damage by casualty in excess of the Threshold Amount with respect to the affected parcel(s), which is not repaired by the Closing Date, then Buyer shall have the right and option to terminate this Agreement, either in total or in relation to the affected parcel, within thirty (30) days after the date of the receipt of notice of casualty or by the Closing Date, whichever first occurs. If Buyer does not elect to terminate this Agreement by such date, or if the casualty is equal to or less than the Threshold Amount, then this transaction shall close without increase or decrease in the Purchase Price and Buyer shall be entitled to all insurance proceeds relating to such repairs and to a credit from Seller at Closing for any deductible.

11.

Defaults and Remedies.

(a)

Buyer’s Default. If Buyer shall default in the observance or performance of Buyer’s obligations under this Agreement and the Closing does not occur as a result thereof (a “Buyer Default”), Seller shall be entitled to recover all out of pocket costs, expenses, or damages incurred by Seller, including reasonable attorneys’ fees, in an amount not to exceed Twenty-five Thousand and No/100 Dollars ($25,000.00). SELLER AND BUYER AGREE THAT IT WOULD BE IMPRACTICAL AND EXTREMELY DIFFICULT TO ESTIMATE THE DAMAGES WHICH SELLER MAY SUFFER UPON A BUYER DEFAULT AND THAT THE DEPOSIT, AS THE CASE MAY BE, REPRESENTS A REASONABLE ESTIMATE OF THE TOTAL NET DETRIMENT THAT SELLER WOULD SUFFER UPON A BUYER DEFAULT. SUCH LIQUIDATED AND AGREED DAMAGES ARE NOT INTENDED AS A FORFEITURE OR A PENALTY WITHIN THE MEANING OF APPLICABLE LAW.

(b)

Seller’s Default. If Seller defaults in any of its obligations to be performed on or before the Closing Date and the Closing does not occur as a result thereof (a “Seller Default”), Buyer shall have the right, subject to the other provisions of this Section 11(b): (i) to seek specific performance of Seller’s obligations hereunder and recover therefrom Buyer’s costs and expenses in connection therewith, including reasonable attorneys’ fees (it being expressly acknowledged by Seller that the remedy of specific performance is an appropriate remedy in the event of Seller Default under this Agreement), provided that any action for specific performance shall be commenced within six (6) months after Buyer delivers written notice of a Seller Default, or (ii) to recover from Seller all out of pocket costs, expenses, or damages incurred by Buyer, including reasonable attorneys’ fees, and terminate this Agreement. Upon delivery of such out of pocket costs, expenses, and damages, this Agreement shall terminate and neither party hereto shall have any further obligations hereunder except for those that are expressly provided in this Agreement to survive the termination hereof. If, however, the equitable remedy of specific performance is not available, Buyer may seek any right or remedy available at law or in equity.

(c)

Survival. The provisions of this Section 11 shall survive the Closing or termination of this Agreement.

12.

Miscellaneous.

(a)

Notices. Any notice required or permitted to be given under this Agreement shall be in writing and (i) personally delivered, (ii) sent by United States registered or certified mail, postage prepaid, return receipt requested, (iii) sent by Federal Express or similar nationally recognized overnight courier service, or (iv) transmitted by electronic mail with a hard copy sent within one (1) Business Day by any of the foregoing means. Such notice shall be deemed to have been given upon the date of actual receipt or delivery (or refusal to accept delivery), as evidenced by the notifying party’s receipt of written or electronic confirmation of such delivery or refusal, if received by the party to be notified between the hours of 8:00 A.M. and 5:00 P.M. Eastern Standard time on any Business Day, with delivery made after such hours to be deemed received the following Business Day. For purposes of notice, the addresses of the parties shall be as follows:


If to Seller:	MakerStar Capital Inc. 4 Park Plaza, Ste 1230 Irvine, CA 92614 Attention: Alex Wang Email: alex@makerstarcapital.com
with a copy to:	MakerStar Capital Inc. Irvine, CA 92614 Attention: Dustin Thomas Email: dustin@makerstarcapital.com
If to Buyer:	CSRE Properties Mississippi, LLC c/o CleanSpark, Inc. 10624 S. Eastern Ave., Ste. A-638 Henderson, NV 89052 Attention: Legal Email: legal@cleanspark.com
with a copy to:	Cozen O'Connor 1717 Main Street, Suite 3100 Dallas, TX 75238 Attention: Steven P. Katkov, Esq. Email: skatkov@cozen.com

or such other address as either party may from time to time specify in writing delivered to the other in accordance with this Section 12(a).

(b)

Brokers and Finders. Neither party has had any contact or dealings regarding the Property, or any communication in connection with the subject matter of this transaction, through any licensed real estate broker or other person who can claim a right to a commission or finder’s fee as a procuring cause of the sale contemplated herein. The provisions of this Section 12(b) shall survive the Closing.

(c)

Successors and Assigns. This Agreement shall be binding upon, and inure to the benefit of, the parties hereto and their respective successors, heirs, administrators and permitted assigns. Buyer shall have the right to assign this Agreement without the consent of Seller. No assignment of this Agreement shall relieve the assignor from primary liability for its obligations hereunder.

(d)

Amendments. Except as otherwise provided herein, this Agreement may be amended or modified only by a written instrument executed by Seller and Buyer.

(e)

Governing Law. This Agreement shall be governed by and construed in accordance with the laws of the State of Mississippi.

(f)

Merger of Prior Agreements. This Agreement and the exhibits hereto constitute the entire agreement between the parties with respect to the purchase and sale of the Property and supersedes all prior agreements and understandings between the parties hereto relating to the subject matter hereof.

(g)

Attorneys’ Fees. In any judicial action or proceeding between or among the parties to enforce any of the provisions of this Agreement regardless of whether such action or proceeding is prosecuted to judgment and in addition to any other remedy, the non-prevailing party shall pay to the prevailing party all out-of-pocket costs and expenses (including reasonable attorneys’ fees and disbursements) incurred therein by the prevailing party. For the purposes of this Section 12(g), the term “prevailing party” shall mean the party which obtains substantially the relief it sought to obtain.

(h)

Business Day. As used herein, the term “Business Day” shall mean a day that is not a Saturday, Sunday or legal holiday in the state where the Property is located. In the event that the date for the performance of any covenant or obligation under this Agreement, or delivery of any notice, shall fall on a non-Business Day, the date for performance thereof shall be extended to the next Business Day.

(i)

Time of the Essence. Time is of the essence of this Agreement.

(j)

Construction. This Agreement has been negotiated by the parties who have had the opportunity to consult their respective counsel. This Agreement shall not be construed more strictly against one party hereto than against any other party hereto merely by virtue of the fact that it may have been prepared by counsel for one of the parties.

(k)

Exhibits. All exhibits are attached hereto and incorporated herein by this reference.

(l)

Headings. Headings at the beginning of any paragraph or section of this Agreement are solely for the convenience of the parties and are not a part of this Agreement or to be used in the interpretation hereof.

(m)

Waiver. No waiver by Buyer or Seller of a breach of any of the terms, covenants, or conditions of this Agreement by the other party shall be construed or held to be a waiver of any succeeding or preceding breach of the same or any other term, covenant or condition herein contained. The consent or approval by Buyer or Seller to or of any act by the other party requiring the consent or approval of the first party shall not be deemed to waive or render unnecessary such party’s consent or approval to or of any subsequent similar acts by the other party.

(n)

Severability. If any phrase, clause, sentence, paragraph, section, article, or other portion of this Agreement shall become illegal, null or void or against public policy, for any reason, or shall be held by any court of competent jurisdiction to be illegal, null or void or against public policy, the remaining portions of this Agreement shall not be affected thereby and shall remain in force and effect to the fullest extent permissible by law.

(o)

Counterparts; Electronic Signatures, This Agreement may be executed in any number of counterparts, each of which shall be deemed an original, and all of which counterparts together shall constitute one agreement. This Agreement may be executed by a party’s signature transmitted by facsimile (“fax”) or by electronic mail in pdf format (“pdf”), and copies of this Agreement executed and delivered by means of faxed or pdf signatures shall have the same force and effect as copies hereof executed and delivered with original signatures. All parties hereto may rely upon faxed or pdf signatures as if such signatures were originals.

(p)

Buyer Disclosure Obligations and SEC Restrictions. Notwithstanding any agreement between Seller and Buyer regarding confidential information or nondisclosure to the contrary, Seller acknowledges that Buyer is a corporation listed on NASDAQ and subject to certain disclosure obligations required by the U.S. Securities and Exchange Commission (“SEC”). Seller and Buyer will work together and cooperate to ensure that press releases and SEC filings in respect of the transfer of the Property are mutually agreed and acceptable, subject to any legal requirements. Seller acknowledges that certain information exchanged in the context of the transfers described in this Agreement may constitute material non-public information under United States federal securities laws, and that United States federal securities laws prohibit any person who has received material non-public information relating to Buyer from purchasing or selling securities of Buyer, or from communicating such information to any person under circumstances in which it is reasonably foreseeable that such person is likely to purchase or sell securities of Buyer. Failure by Seller to adhere to the provisions of this shall constitute a material breach of this Agreement.

(q)

1031 Exchange. Seller and/or Buyer may wish to effect a I.R.C. Section 1031 tax-deferred exchange and both parties agree to cooperate to facilitate such exchange;

provided, however, that the exchanged property shall be directly deeded to the party effecting such exchange, neither party shall incur additional cost or expense on the other party’s behalf, and such exchange shall not cause any delays in the time periods or scheduled Closing Date specified in this Agreement.

* * * * * *

{Signatures Follow}

IN WITNESS WHEREOF, the parties hereto have executed this Agreement as of the date first set forth above.

SELLER:

MAKERSTAR CAPITAL, INC.,

a Delaware corporation

By: /s/ Shengyin Chen .

Name: Shengyin Chen .
Its: CEO .

[Seller signature page to Purchase and Sale Agreement – Clinton, Mississippi properties]

BUYER:

CSRE PROPERTIES MISSISSIPPI, LLC,
a Mississippi limited liability company

By: /s/ Zachary Bradford .
Name: Zachary Bradford .
Its: Manager .

[Buyer signature page to Purchase and Sale Agreement – Clinton, Mississippi properties]

CONSTRUCTION MANAGEMENT SERVICES AGREEMENT

THIS AGREEMENT is entered into as of the 16th day of September 2024, by and between Beast Power, Inc. (“Construction Manager”), and CSRE Properties Mississippi, LLC (“Owner”) (this “Agreement”).

WHEREAS, Owner is an owner and operator of data center facilities; and

WHEREAS, Construction Manager specializes in sourcing, developing, building, and selling data center facilities; and

WHEREAS, Construction Manager, through its affiliates, was the prior owner of certain real property and assets, including construction contracts (individually and collectively, the “Construction Contract”) with Wesley Jones and Construction Manager (individually and collectively, the “Contractor”), for the construction of the infrastructure and buildings to the specifications and expectations of Owner sufficient to operate 16.5 MW of bitcoin mining facilities in Clinton, Mississippi (the “Project”); and

WHEREAS, under separate transactions, including a Purchase and Sale Agreement and a Membership Interest Purchase Agreement of this same date, both of which are incorporated herein by reference and may, along with this Agreement, collectively be referred to as the “Transaction Documents”, Owner, directly and through its affiliates, has purchased the real property and assets and is assuming the Construction Contract for the Project; and

WHEREAS, Owner desires to engage Construction Manager to manage the Project, including, but not limited to, overseeing the build-out, Project safety, tracking of delivery and deployment of fixtures, equipment and materials from the current state of the Project to final completion, together with the provision of all necessary services and to prepare deliverables that are described in the scope of services and to ensure the construction of the Project meets or exceeds the minimum specifications, standards and requirements set forth in Exhibit A (collectively, the “Services”) in connection with the Project; and

WHEREAS, Construction Manager is willing to perform the Services for Owner, subject to the terms and conditions set forth below.

NOW, THEREFORE, in consideration of the mutual promises contained herein, the parties agree as follows:

Services

Construction Manager agrees to perform for Owner the Services set forth herein and in Exhibit A and to ensure that the construction meets or exceeds the minimum specifications and standards set forth herein and in Exhibit A, which is attached hereto and incorporated by reference, and includes the usual and customary construction phase services. Exhibit A is attached solely for the purpose of describing the Services to be performed by Construction Manager and setting forth certain minimum specifications and standards to which the construction must meet

or exceed. In the event of a conflict between this Agreement and Exhibit A, this Agreement shall govern and control. Construction Manager may subcontract some of the Services to be performed by Construction Manager; provided, however, Construction Manager must obtain Owner’s advance written consent before subcontracting Services, and Construction Manager shall remain responsible for all Services, whether performed by Construction Manager or by a subcontractor or consultant to Construction Manager.

Construction Manager shall provide and furnish all labor, materials, and equipment necessary for complete and full performance of the Services. Construction Manager shall provide the Services in accordance with the terms of this Agreement, including any exhibits attached hereto.

Construction Manager shall submit to Owner a schedule for the performance of its Services, which shall be subject to Owner’s approval. Once approved by Owner, the schedule shall be attached to this Agreement as Exhibit B and Construction Manager shall be obligated to perform its Services in accordance with the schedule, which may only be modified by a writing executed by both parties. Owner shall be entitled to recover from Construction Manager any additional costs that Owner incurs relating to Construction Manager’s or Contractor’s failure to perform the Services in accordance with the approved schedule.

Construction Manager shall comply with all laws, statutes, ordinances, regulations, codes, and orders of local authorities applicable to the Services, including, but not limited to, all federal, state and local occupational, safety, and health acts.

Construction Manager shall be responsible for initiating, maintaining, and supervising all safety precautions and programs in connection with the performance of the Services. Construction Manager shall pay or contest all fines levied against Owner, Construction Manager or Contractor caused by or resulting from Construction Manager’s, Contractor’s, or any of their respective subcontractor’s or subconsultant’s failure to comply with any safety rules, regulations, laws, ordinances, orders, or standards. If Construction Manager fails to pay or contest such fines, Owner may, upon written notice to Construction Manager, pay the same and deduct such amount from monies due or to become due to Construction Manager under this Agreement, the Transaction Documents or any other contracts or arrangements between Construction Manager and Owner (directly or through any of their affiliated entities).

If Owner wishes to change the scope of Services or wishes to obtain additional Services, Owner shall notify Construction Manager and provide a description of such changed or additional Services. After receipt of such notice, Construction Manager shall provide to Owner a Change Order Request identifying the increase or decrease, if any, to the Compensation (as defined below) and the impact, if any, on the approved schedule associated with the performance of the changed or additional Services. If Owner agrees with the Change Order Request, Owner and

Construction Manager shall execute a Change Order stating their agreement upon the scope of the changed or additional Services, the amount of the adjustment, if any, to the Compensation, and the extent of the adjustment, if any, to the schedule associated with the changed or additional Services. If Owner and Construction Manager cannot agree on the terms of a Change Order, then Owner shall issue a Change Directive. Upon receipt of a Change Directive, Construction Manager shall promptly proceed with performance of the changed or additional Services. Construction Manager shall not be entitled to compensation of any kind for changed or additional Services unless such Services are authorized by Owner in writing before Construction Manager or Contractor commences the performance of such Services. Construction Manager shall not be entitled to any additional compensation for Services made necessary by any fault or omission of Construction Manager, Contractor, or any of their respective subcontractors or subconsultants to perform the duties, responsibilities, or obligations under this Agreement or any contracts or agreements relating to the performance of the Services and Contractor’s Work. Notwithstanding anything herein to the contrary, Owner reserves the exclusive right to direct changes to the Contractor’s Work or services and issue change orders directly to the Contractor at Owner’s sole discretion and without additional compensation to the Construction Manager.

Construction Manager shall, in the performance of the Services, only employ or use labor capable of working harmoniously with all trades, crafts and any other individuals associated with the Project. Construction Manager shall take reasonable measures to minimize the likelihood of any strike, work stoppage or other disturbance and shall work diligently to resolve in a timely manner any such events that should occur. These measures shall be taken without additional compensation from Owner.

Owner may acquire or enter into contracts pursuant to a separate transaction and or may also be or become a party to agreements with design professionals, contractors, and other consultants that Owner believes are necessary for the Project. Construction Manager shall (a) cooperate and work with Contractor and all such design professionals, contractors, and other consultants to the extent necessary for the performance of the Services or for the benefit of the Project, (b) coordinate the information shown in Construction Manager’s documents with the Contractor, design documents of other architects, contractors, fabricators, suppliers and consultants, and (c) coordinate the approved schedule for the performance of the Services with the overall Project schedule.

Compensation and Payment.

As compensation for the Services, Owner shall pay to Construction Manager $2,887,500.00 (Two Million, Eight Hundred Eighty-Seven Thousand, Five Hundred Dollars and Zero Cents (the “Total Payment”) less an offset of all amounts paid by Owner in connection with the Project, including, without limitation: (1) the amounts paid by Owner to the Contractor, or any other trade, supplier, fabricator,

design professional or third-party engaged in connection with the Project, the costs of any permits, testing or inspections, or taxes, the additional labor, materials, fixtures and equipment purchased, and any other costs or expenses reasonably anticipated to have been a cost that an entity in the position of Owner would have paid to fully complete and turn-over the Project by the Completion Date; (2) tax payments relating to the underlying real or personal property and any sales and use taxes relating to the assets purchased under the Real Estate Purchase Agreement or the Membership Interest Purchase Agreement, if any, which would have arisen prior to the date of this Agreement; and (3) any other offset for any other rights and remedies Owner or its affiliates are entitled to against Construction Manager or its affiliates pursuant to any other agreement or Transaction Document, at law, in equity, or otherwise, including, without limitation, the Real Estate Purchase Agreement or the Membership Interest Purchase Agreement (collectively, the “Offset Amounts”) (the “Total Payment” less the “Offset Amounts” is referred to herein as the “Compensation”).

Provided Construction Manager has complied with its obligations under this Agreement and the Work conforms with the requirements set forth herein and is completed and ready for use and occupancy for its intended purposes by the Completion Date, and subject to the Offset Amounts, the Compensation shall be payable to Construction Manager in three payments in and as set forth in the Membership Interest Purchase Agreement and as follows:

$1,443,750.00 (One Million, Four Hundred Forty-Three Thousand, Seven Hundred-Fifty Dollars and Zero Cents) payable upon the completion of the first half of construction as certified by and acceptable to Owner, and within ten (10) business days of Owner’s receipt of Construction Manager’s first application for payment as set forth herein (the “First Payment”);

ii.

$943,750.00 (Nine Hundred Forty-Three Thousand, Seven Hundred-Fifty Dollars and Zero Cents) payable upon energization as certified by and acceptable to Owner, issuance of the Certificate of Substantial Completion, and within ten (10) business days of Owner’s receipt of Construction Manager’s second application for payment as set forth herein (the “Second Payment”); and

iii.

$500,000.00 (Five Hundred Thousand Dollars and Zero Cents), which payment is contingent upon completion of an internal electrical evaluation certified by and acceptable to Owner and payable within thirty (30) days of issuance of the Final Certificate of Completion as set forth herein (the “Final Payment”).

Under no circumstance shall the amounts paid by Owner or for which Owner may be liable in connection with the Project exceed the Total Payment amount. Construction Manager agrees to be solely responsible and liable to Owner and its affiliates for all Offset Amounts in excess of the Total Payment. To the extent Owner intends to withhold any amount from its payments to Construction Manager, Owner shall provide advance written notice to Construction Manager identifying the amount of and basis for the withholding. In the event the Offset Amounts,

Liquidated Damages and/or any other damages or costs to which Owner or its affiliates may be entitled pursuant to this Agreement, the Transaction Documents, any other contracts or agreements or at law exceed the Total Payment amount, Construction Manager shall not be entitled to any Compensation or payment hereunder, and Construction Manager shall pay to Owner the difference within thirty (30) days of Construction Manager’s receipt of Owner’s accounting and demand for payment.

Construction Manager shall be responsible for payment of all its contractors and consultants, of any tier, without reimbursement from Owner other than as set forth in this Agreement.

Construction Manager’s acceptance of the Compensation pursuant to this Agreement shall release Owner from all claims, demands and causes of action arising out of or relating to this Agreement and the Services, except for those that have been previously identified by Construction Manager in writing and confirmed in a writing executed by both parties as unresolved as of the time of payment.

Period of Performance and Payment.

This Agreement shall take effect on the date set forth above and shall terminate upon final payment to Construction Manager following Final Completion of all Services unless the Agreement is terminated earlier pursuant to Paragraph 10. Any Services provided by Construction Manager before the date set forth above shall nevertheless be subject to and governed by the terms of this Agreement.

Time is of the essence with this Agreement, and Construction Manager shall complete the Services within the period specified in the approved schedule described in Paragraph 1(c), which in no event shall exceed the overall Completion Date as defined herein.

Substantial Completion. “Substantial Completion” for purposes of this Agreement shall mean the stage in the progress of the Work when the Project is sufficiently complete in accordance with this Agreement and the Contract Documents so that Owner can occupy or utilize the Project for its intended use, meets or exceeds the minimum specifications and standards set forth in Exhibit A, and a Certificate of Occupancy and all other approvals required under applicable permits have been issued by governmental authorities with jurisdiction over the Project. Substantial Completion shall be achieved no later than sixty (60) calendar days after full execution of this Agreement (the “Completion Date”).

In the event Construction Manager shall fail to progress the Work or fall behind schedule at any time, for any reason, such that there exists reasonable cause that the Completion Date may not be met, or as otherwise reasonably requested by Owner, Construction Manager shall develop and deliver a recovery plan to Owner with a recovery schedule and a program describing the additional manpower, overtime, material expediting, re-sequencing of the Work and other steps Construction

Manager and the Contractor shall take to meet the Completion Date. If Construction Manager fails to do so or Owner reasonably determines that the Completion Date may not be met, Owner reserves the right, in Owner’s sole discretion, to direct the Contractor or others to undertake any such recovery efforts and include the costs of such efforts as Offset Amounts reducing the Total Payment. No approval or consent by Owner of any plan for re-sequencing or acceleration of the Work submitted by Contractor, or Owner direction to the Contractor or others to undertake any recovery efforts, shall constitute a waiver by Owner of any other rights or remedies pursuant to this Agreement, including, without limitation, the assessment of Liquidated Damages.

When Construction Manager considers that the Work, or a portion thereof which Owner agrees to accept separately, is substantially complete, Construction Manager shall prepare and submit to Owner a comprehensive list of items to be completed or corrected prior to final payment. Failure to include an item on such list does not alter the responsibility of the Construction Manager to ensure completion of all Work in accordance with this Agreement and the Contract Documents.

Upon receipt of Construction Manager’s list, Owner or any consultants or representatives designated by Owner will inspect to determine whether the Work or designated portion thereof is substantially complete. If Owner’s inspection discloses any item, whether or not included on Construction Manager’s list, which is not sufficiently complete in accordance with this Agreement and the Contract Documents, including any of the minimum specifications or standards, or that so Owner can occupy or utilize the Work or designated portion thereof for its intended use, Construction Manager shall complete or correct such item immediately upon notification by Owner. In such case, Construction Manager shall then submit a request for another inspection by Owner to determine Substantial Completion.

When the Work or designated portion thereof is substantially complete to Owner’s satisfaction in accordance with the Contract Documents and a Certificate of Occupancy and all other approvals required under applicable permits have been issued by governmental authorities having jurisdiction over the Project, Owner will issue a Certificate of Substantial Completion that will establish the date of Substantial Completion; establish responsibilities of Owner and Construction Manager for security, maintenance, heat, utilities, damage to the Work and insurance; and fix the time within which Construction Manager shall finish all items on the list accompanying the Certificate.

First Payment. At any time at or after completion of the first half of construction, Construction Manager may submit an application for payment to Owner for the First Payment together with a Partial Release of Liens and Claims in the form attached as Exhibit C notarized and executed by Construction Manager, Contractor and all subcontractors, suppliers and consultants performing any work or services on the Project, and such other documentation as Owner may reasonably require. Provided Construction Manager has complied with its obligations under this Agreement and subject to Owner’s inspection and approval of the Work and

certification of the status of completion, within ten (10) business days of Owner’s receipt of Construction Manager’s first application for payment and the required release of liens and claims, proper in form and substance, Owner will make the First Payment to Construction Manager, less all Offset Amounts, Liquidated Damages and withholdings. With prior written notice to Construction Manager, the First Payment may be further adjusted by Owner for any Work that is incomplete or not in accordance with the requirements of this Agreement and the Contract Documents or as otherwise reasonably determined to protect Owner’s commercial interests

Second Payment. At any time after issuance of the Certificate of Substantial Completion and energization, Construction Manager may submit an application for payment to Owner for the Second Payment together with a Partial Release of Liens and Claims in the form attached as Exhibit C notarized and executed by Construction Manager, and Final Releases of Liens and Claims in the form attached as Exhibit D notarized and executed by Contractor and all subcontractors, suppliers and consultants performing any work or services on the Project, and such other documentation as Owner may reasonably require. Provided Construction Manager has complied with its obligations under this Agreement and subject to Owner’s inspection and approval of the Work and certification of the status of completion, within ten (10) business days of Owner’s receipt of Construction Manager’s second application for payment and the required release of liens and claims, proper in form and substance, Owner will make the Second Payment to Construction Manager, less all Offset Amounts, Liquidated Damages and withholdings. With prior written notice to Construction Manager, the Second Payment may be further adjusted by Owner for any Work that is incomplete or not in accordance with the requirements of this Agreement and the Contract Documents or as otherwise reasonably determined to protect Owner’s commercial interests.

Final Completion and Final Payment. “Final Completion” for purposes of this Agreement shall mark the ultimate conclusion of the Project and be the date on which all Work has been fully and finally completed, including, without limitation, an internal electrical evaluation, and all punch list items, deficiencies, and outstanding obligations of Construction Manager or Contractor have been addressed, rectified and finished in accordance with this Agreement, and all requirements of the Contract Documents and Transaction Documents to Owner’s satisfaction and approval, and all required close-out documentation has been submitted to Owner. Neither Final Payment nor any remaining retained amounts shall become due until Construction Manager submits to Owner (1) an affidavit that payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which Owner or Owner’s property might be responsible or encumbered have been paid or otherwise satisfied, (2) a certificate evidencing that insurance required by the Contract Documents to remain in force after Final Payment is currently in effect, (3) all record drawings, as-built documents, O&M manuals and warranty materials applicable to the Work, (4) documentation of any special warranties, such as manufacturers’ warranties or specific Contractor or subcontractor warranties, (5) Final Releases of Liens and claims in the form

attached as Exhibit D notarized and executed by Construction Manager, and (6) such other documentation as Owner may reasonably require or other data establishing payment or satisfaction of obligations, liens, claims, security interests, or encumbrances arising out of the Project, to the extent and in such form as may be reasonably designated by Owner. If Contractor or any subcontractor or consultant refuses to furnish a release or waiver required by Owner, Construction Manager may furnish a bond satisfactory to Owner to indemnify the Owner Indemnified Parties against such lien, claim, security interest, or encumbrance. If a lien, claim, security interest, or encumbrance remains unsatisfied after payments are made, Construction Manager shall refund to Owner all money that Owner may be compelled to pay in discharging the lien, claim, security interest, or encumbrance, including all costs and attorneys’ fees.

Upon receipt of Construction Manager’s notice that the Work is ready for final inspection and acceptance and upon receipt of a final application for payment together with all close-out documentation required as a condition precedent to Final Payment, Owner will make such inspection. When Owner finds the Work acceptable under this Agreement and the Contract Documents and the Agreement fully performed, Owner will notify Construction Manager and issue a Final Certificate for Payment. Within thirty (30) days of the issuance of a Final Certificate for Payment, Owner will make the Final Payment to Construction Manager, less all Offset Amounts, Liquidated Damages and withholdings. With prior written notice to Construction Manager, the Final Payment may be further adjusted by Owner for any Work that remains incomplete or not in accordance with the requirements of this Agreement, the Contract Documents, the Transaction Documents or other agreements or as otherwise reasonably determined to protect Owner’s commercial interests.

Liquidated Damages. Construction Manager understands that if Substantial Completion is not achieved by the Completion Date (as defined above), Owner will suffer damages that are difficult to determine and accurately specify. Therefore, Construction Manager agrees that if Substantial Completion is not achieved by the Completion Date, unless such delay is caused by Entergy delaying their completion of high voltage work, Construction Manager shall pay to Owner as liquidated damages, and not as a penalty, the sum of $10,000.00 (Ten Thousand Dollars and Zero Cents) for each calendar day after the Completion Date until Substantial Completion is achieved. Owner shall have the right to withhold or offset from payments otherwise due to Construction Manager or any of its affiliates, or otherwise charge Construction Manager, any liquidated damages assessed pursuant to this Section.

In the event Construction Manager’s performance of its obligations under this Agreement is delayed due to causes beyond Construction Manager’s and Owner’s control, including, but not limited to, acts of God or public enemy, governmental authority of any nature, fires, strikes, floods, pandemics, epidemics, abnormal weather, war, or riot (“Force Majeure Events”), then the time for performance hereunder shall be extended a period of time equivalent to the duration of the delay

that is approved by Owner in writing, and Construction Manager shall not be liable for any damage to Owner resulting from such Owner-approved delay; provided, however, that Construction Manager shall promptly notify Owner of such delay in writing, and shall use all reasonable efforts to mitigate any adverse consequences from the Force Majeure Event causing the delay. The extension of time described herein shall be Construction Manager’s sole remedy for delays caused by Force Majeure Events, and Owner shall not be liable for any additional payments to or damages of Construction Manager for delays caused by Force Majeure Events.

Contractual Status. In performing the Services under this Agreement, Construction Manager shall operate as, and have the status of, an independent contractor and shall not act as, or be, an agent or employee of Owner, and has no power to bind Owner or to assume any obligations or liabilities on behalf of Owner. Construction Manager shall not represent to any person that it has any such authority.

Construction Manager’s Standard of Care.

Construction Manager represents that all Services provided pursuant to this Agreement: (a) will conform with the terms of this Agreement; (b) will be performed in a good, skillful, and workmanlike manner and meet or exceed the minimum specifications and standards set forth herein and in Exhibit A; (c) will be performed by the proper number of experienced, skilled, and licensed personnel, qualified by education and/or experience to perform their assigned tasks; and (d) will be performed as expeditiously as is consistent with such skill and care and the orderly progress of the Project and so as to not delay the overall Project schedule. Construction Manager accepts the relationship of trust and confidence established between Construction Manager and Owner under this Agreement and agrees to perform the Services consistent with that degree of professional skill and care that is customarily provided by similar professionals or Construction Managers practicing in similar localities under similar circumstances. Construction Manager shall perform its Services in the most expeditious and economical manner that is consistent with the interests of Owner and the applicable standard of care.

Construction Manager shall be responsible for the quality, technical accuracy and completeness of all Services furnished and documents or deliverables prepared pursuant to this Agreement and the Work performed by the Contractor. Construction Manager understands that Owner will be relying upon the accuracy, competence and completeness of the Services and all documents and deliverables prepared by Construction Manager.

Construction Manager represents that it possesses the professional and technical expertise and is properly qualified, registered and, where required, licensed to perform the Services under this Agreement.

Except with the Owner’s knowledge and written consent, Construction Manager shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Construction Manager’s judgment

with respect to the Project.

All deliverables, including, but not limited to documents and reports, to be prepared in connection with the Services shall be technically correct. Any plans, drawings or specifications that, under applicable law, require the seal of a professional architect or engineer, shall be sealed by an architect or engineer duly licensed under the laws of the state in which the Project is located.

Construction Manager shall retain all Project related documents and information it receives, and Owner shall have access to the documents and information. Construction Manager shall transmit the documents and information to the Owner at Final Completion or upon Owner’s request.

Indemnification

To the fullest extent permitted by law, Construction Manager shall defend, indemnify and hold harmless Owner, CleanSpark, Inc., Clinton16.5 LLC, and their respective affiliated companies, and all of their respective directors, officers, agents, members and employees (individually and collectively, the “Owner Indemnified Parties”) from any claims, damages, suits, liens, costs or expenses, including, but not limited, reasonable expert witnesses’ and attorneys’ fees, to the extent arising out of or resulting from the negligence, intentional misconduct, gross negligence or breach of the Agreement (including, but not limited to, any failure to timely perform under their respective agreements) by Construction Manager, Contractor, or any of their respective subcontractors or subconsultants, or employees or agents of any of them in connection with performance of the Services described in this Agreement and completion of the Project; provided, however, the indemnification obligation set forth in this Paragraph shall not apply in the case of claims arising from the sole negligence of an indemnified party.

Construction Manager shall be responsible for all damages and expenses on account of or related to injuries, including disease or death, to or of any of its employees or agents, or those of Contractor, or any of their respective subcontractors or subconsultants, while on the premises of Owner or performing any part of the Services, and Construction Manager shall defend, indemnify, and hold harmless the Owner Indemnified Parties from all claims, damages, suits, costs, or expenses, including, but not limited to, reasonable expert witnesses’ and attorneys’ fees, that may arise in relation to, as a result of, or as a consequence of such injuries, disease or death.

The provisions of this Paragraph 6 are not limited by the provisions of any insurance program and/or policy maintained by or on behalf of Construction Manager (including, but not limited to, any Worker’s Compensation Insurance) or by any limitation on amount or type of compensation payable by or for Construction Manager, Contractor, or any of their respective subcontractors or subconsultants under any workers’ compensation acts, disability benefit acts, or other employee benefit acts.

Construction Manager shall perform its obligations under this Paragraph 6 at no additional cost or expense to Owner. The provisions of this Paragraph 6 shall survive the completion of the Services hereunder or the expiration, cancellation or termination of this Agreement.

Deficient Services. In addition to and not in limitation of any other rights and remedies of Owner in connection with the Services, Construction Manager agrees to re-perform and to correct at its sole expense any Services performed by Construction Manager pursuant to this Agreement that fail to comply with the requirements of this Agreement, including any exhibits hereto, and to re-perform and to correct any Services that fail to meet or conform with the standard of care that Construction Manager has accepted pursuant to Paragraph 5 or any of the minimum specifications and standards set forth in Exhibit A. Construction Manager shall reimburse Owner for, or, at Owner’s sole discretion, Owner may offset against any amounts otherwise due to Construction Manager or its affiliates for any additional costs that may be incurred by Owner relating to Construction Manager’s failure to properly perform the Services required by this Agreement.

Insurance. Construction Manager shall, at its own cost and expense, procure and maintain, in full force and effect, at all times during the term of this Agreement, the insurance specified in Exhibit E. All insurance shall be placed with insurers acceptable to Owner and licensed to do business in the state where the Services under this Agreement are to be performed. No acceptance by Owner of any Certificate of Insurance required hereunder shall constitute or be construed as a waiver by Owner of the insurance requirements of this Agreement, the compliance with which shall be the sole responsibility of Construction Manager. Construction Manager’s failure to maintain the insurance required by this Agreement shall be deemed a material breach by Construction Manager.

The policies required by this Paragraph shall include endorsements specifying that the coverage afforded by them is, and shall be, primary to any coverage available to Owner or other additional insureds on a non-contributory basis.

All policies of insurance required under this Paragraph 8, except for Worker’s Compensation and Professional Liability Insurance, shall name the following as additional insureds thereunder: Owner, CleanSpark, Inc., and their respective affiliated companies, members, directors, officers, agents, representatives and employees.

Confidentiality.

Construction Manager agrees that it, its employees, subcontractors, subconsultants and agents shall not, during or at any time after the term of this Agreement, directly or indirectly publish or disclose to any third party any information of any kind or nature acquired, derived or in any way arising out of Construction Manager’s Services performed for Owner, without the prior written authorization of Owner. This provision shall survive the termination or expiration of this Agreement.

Construction Manager shall hold in trust and confidence all information obtained directly or indirectly in or through the files or records of Owner, or disclosed in connection with the Services provided under this Agreement, and shall disclose and utilize such information only in connection with and to the extent necessary for the performance and completion of the Services.

10.

Termination.

Owner may terminate this Agreement for Owner’s convenience, without cause of any kind, by providing written notice to Construction Manager. In such event, Construction Manager, as its sole and exclusive remedy, shall be entitled to receive any Compensation that may be due to it under the terms of this Agreement, if any after all offsets and expenses to which Owner is entitled as set forth herein, for that portion of the Services actually and properly completed in accordance with the terms of this Agreement prior to the date of the notice of termination. In no event shall Construction Manager be entitled to any other payments or damages from Owner, including, but not limited to, overhead, profit or fees on Services not performed.

In the event Construction Manager materially breaches the terms of this Agreement, Owner, in addition to any other rights and remedies provided by the Agreement or by law, shall have the right to terminate this Agreement for cause. In that event, Owner shall provide fourteen (14) days’ prior written notice to Construction Manager. Absent a cure by Construction Manager within such period, the termination for cause shall be deemed effective, entitling Owner to withhold any payments that might otherwise have been due to Construction Manager and to recover from Construction Manager all direct and consequential damages arising out of or relating to Construction Manager’s failure to perform or breach of the Agreement. If any termination of Construction Manager for cause is later determined to have been improper, the termination shall automatically convert to a termination for convenience under subparagraph (a) hereof.

11.

Dispute Resolution. Claims, disputes or other matters in question between the parties to this Agreement arising out of or relating to this Agreement or the breach thereof shall be resolved through litigation in a court of competent jurisdiction in the county where the Project is located. In the event of litigation, THE PARTIES WAIVE THEIR RIGHT TO A JURY TRIAL. To the extent the underlying Construction Contract or any other contract or agreement pertaining to the Project includes a different dispute resolution provision, Construction Manager consents to resolve any claims, disputes or other matters in question between the parties to this Agreement arising out of or relating to this Agreement or the breach thereof through the forum and in the jurisdiction specified in the Construction Contract or such other contract or agreement, at Owner’s sole election.

12.

Audit and Inspection of Records. Owner reserves the right to inspect, copy and audit the records of Construction Manager, Contractor, and any of their respective subcontractors or subconsultants (“Construction Manager’s Records”) in connection with all matters related

to this Agreement to evaluate compliance of Construction Manager, Contractor and/or any of their respective subcontractors or consultants with governmental and legal requirements, as well as requirements of the Agreement. Owner shall also have the right to examine and audit Construction Manager’s Records, if necessary, to permit adequate evaluation of cost and pricing data related to Change Directives, along with the computations and projections used therein.

13.

Work for Hire.

Construction Manager agrees that all writings, works of authorship (including any software, program codes and any documentation), notes, schedules, reports and memoranda produced, developed or authored by Construction Manager during the course of performing Services for Owner (collectively, the “Writings”) are “works for hire” and the property of Owner, including, but not limited to, any copyrights pertaining thereto. Construction Manager further agrees to include and enforce such provisions in contracts with any subcontractors or subconsultants and contracts of employment of individuals engaged in the performance of Services for Owner as shall be necessary to ensure the exclusivity of ownership provided for herein. This provision shall survive the termination of this Agreement for any reason.

Construction Manager acknowledges and agrees that the Project is the property of Owner and Construction Manager may not use: (i) any Project-related studies, reports, analyses, drawings, specifications, guidelines or plans (“Work Product”) for any purpose not relating to the Project; or (ii) Owner’s name or logo, without Owner’s prior written consent. Upon completion of the Services, or if this Agreement is terminated by Owner before completion of the Services, Construction Manager shall submit to Owner two (2) full and complete reproductions of Construction Manager’s Work Product, including, but not limited to, as applicable, copies of the data files generated by Construction Manager’s word processing, REVIT modeling or computer aided design (“CAD”) facilities in native and *.PDF format on CD or DVD. All such reproductions shall be the property of Owner, which may use them without Construction Manager’s permission for any proper purpose relating to the Project, including additions to or completion of the Project, or any subsequent planning, development, design or construction work with respect to the Project, whether or not Construction Manager is employed to provide further services in connection therewith.

14.

Proprietary Rights Indemnification. Construction Manager shall defend, indemnify and hold harmless the Owner Indemnified Parties from and against any and all damages, costs, losses, liability and expenses (including, but not limited to, reasonable expert witnesses’ and attorneys’ fees) and any other liability of Owner or any Owner Indemnified Parties to third parties arising out of or in connection with a claim that the Services rendered or any documentation provided by Construction Manager hereunder infringes upon any trade secret, copyright, trademark, patent, or other proprietary or contractual right of any third party.

15.

Notice. Any notice, request or other communication to either party by the other as provided for herein shall be given in writing, sent by first-class mail, return receipt requested or by overnight courier, and shall be deemed given upon actual receipt by the addressee. Notices shall be addressed as follows:

If to Owner:

Leighton Koehler

General Counsel

CleanSpark

10624 S. Eastern Ave. A-638

Henderson, NV 89052

lkoehler@cleanspark.com

If to Construction Manager:

Alex Wang

COO

Beast Power, Inc.

4 Park Plaza, Ste 1230
Irvine, CA 92614

Either party may change the recipient or address for receiving notices upon written notice to the other party.

16.

Permits. Construction Manager shall obtain all permits, licenses, or notifications required by local, county, state, or federal agencies for the Services described in this Agreement or the underlying Construction Contract with Contractor.

17.

Emergencies. In an emergency affecting the safety of persons or property, where it is impracticable for Construction Manager to obtain immediate authorization from Owner, Construction Manager shall act, at its discretion, to prevent threatened damage, injury, or loss.

18.

Laws and Regulations. At all times during the performance hereunder, Construction Manager and its employees and representatives shall comply with, and Construction Manager shall cause Contractor, and their respective subcontractors and subconsultants to comply with, all applicable federal, state and local laws, ordinances, statutes, codes, standards, rules, regulations and orders presently in effect and becoming effective during the performance of Services hereunder and with Owner’s rules and regulations and shall be responsible as set forth in this Agreement for all consequences including, but not limited to, paying all fines and penalties that may arise because of noncompliance of Construction Manager, Contractor, or any of their respective subcontractors or subconsultants with such requirements.

19.

Discharge of Liens. If Contractor or any of Construction Manager’s or Contractor’s

subcontractors, subconsultants, or suppliers, of any tier, file a lien against the Project, Construction Manager shall, within seven (7) days of receipt of notice from Owner, cause any such liens to be released by procuring and recording a bond or otherwise arranging for the removal of the lien. If Construction Manager does not cause the lien to be released and discharged or removed, Owner shall have the right to pay all sums necessary to obtain such a release and discharge, and to cause the costs it incurs in doing so (including reasonable attorneys’ fees) to be paid by Construction Manager or offset against any amounts owed to Construction Manager. Construction Manager shall indemnify, defend, and hold harmless the Owner Indemnified Parties from all claims, losses, demands, and causes of action or suits of whatever nature arising out of any such lien. Construction Manager’s obligation to indemnify in this Paragraph 19 shall be in addition to Construction Manager’s obligations to indemnify set forth elsewhere in this Agreement.

20.

Cumulative Remedies. Owner’s rights and remedies provided herein are cumulative and are in addition to and not in substitution for any other rights and remedies pursuant to any other agreement, guarantee or Transaction Document, at law, in equity, or otherwise. Notwithstanding anything to the contrary in this Agreement or any other agreement, guarantee or Transaction Document, and without prejudice to any other right or remedy Owner has or may have (whether under this Agreement, any other agreement, guarantee or Transaction Document, at law, in equity or otherwise), if Owner or any affiliate of Owner has any claim for damages against Construction Manager or any affiliate of Construction Manager, or is entitled to indemnification, offset, setoff, or any other amount under any other agreement, guarantee or Transaction Document with Construction Manager or any affiliate of Construction Manager, including, without limitation, the Real Estate Purchase Agreement and/or the Membership Interest Purchase Agreement, Owner, in its sole discretion, may elect to recover such damages, liabilities, indemnification or other such amounts by seeking cash directly from Construction Manager pursuant to this Agreement, or by setting off such amounts against the Total Payment or any other liability that Owner owes to Construction Manager under this Agreement, regardless of whether any such liability is matured or unmatured, liquidated or unliquidated.

21.

Waiver. Any waiver by either party of any provisions or conditions of this Agreement shall not be construed or deemed to be a waiver of any other provisions or conditions of this Agreement, nor a waiver of a subsequent breach of the same provision or condition, unless such waiver be expressed in writing by the party to be bound.

22.

General.

Modification - This Agreement constitutes the entire agreement between the parties and supersedes all prior representations, understandings or agreements between the parties, whether oral or written, concerning the subject matter hereof. This Agreement or any part hereof may not be changed, amended or modified, except by written agreement of the parties as signed by the duly authorized representatives of both parties.

No Assignment - This Agreement and the obligations hereunder may not be

assigned or transferred by Construction Manager.

Contractors and Consultants - Owner reserves the right to approve in advance any Contractor or consultant, of any tier, or any other sub-professional of Construction Manager to be used in the performance of Services or the Work hereunder.

Governing Law - This Agreement shall be governed by and construed in accordance with the laws of the state in which the Project is located.

Severability - If any part of this Agreement is determined to be invalid, illegal or unenforceable, as written or applied, such determination shall not affect the validity, legality or enforceability of any other part of this Agreement; and the remaining parts shall be enforced as if such invalid, illegal, or unenforceable part were not contained herein and to the fullest extent permitted by law.

Headings - The headings contained herein are inserted for convenience of reference only and in no way define, limit or extend the scope or intent of this Agreement or any provision hereof.

Counterparts - This Agreement may be executed simultaneously or in counterparts, each of which will be deemed an original, but all of which together will constitute one and the same Agreement. Facsimile, photocopy, PDF, or other copied signatures shall be considered as original signatures for all purposes.

23.

Exhibits. The following Exhibits are attached to and made a part of this Agreement:

EXHIBIT “A” – Scope of Services

EXHIBIT “B” – Schedule

EXHIBIT “C” – Partial Waiver and Release of Liens and Claims

EXHIBIT “D” – Final Waiver and Release of Liens and Claims

EXHIBIT “E” – Certificate of Insurance/Insurance Requirements

EXHIBIT “F” – Construction Contract

[SIGNATURES APPEAR ON NEXT PAGE]

IN WITNESS WHEREOF, the parties hereto have caused this Agreement to be executed by their duly authorized representatives or agents as of the day and year first hereinabove written.

CSRE Properties Mississippi, LLC

By: /s/ Zachary Bradford .

Name, Title: Zachary Bradford, Manager

Beast Power, Inc.

By: /s/ Shengyin Chen .

Name, Title: Shengyin Chen, CEO

[Signature page to Construction Management Services Agreement]

CleanSpark Acquires Two Additional

Sites in Mississippi and Closes Second Site in Wyoming

LAS VEGAS, September 17, 2024 -- CleanSpark Inc. (Nasdaq: CLSK), America’s Bitcoin Miner® (the "Company") today announced it has acquired two Bitcoin mining sites and associated land near Clinton, Mississippi, and closed on its second site in Wyoming.

The Mississippi acquisitions have a combined purchase price of $5.775 million and will support a total of 16.5 MW. The sites are currently partially complete and the purchase price includes the cost to complete construction of the site infrastructure. The site will be delivered to the Company turnkey ready with an expected completion date of December 1, 2024. Upon completion and installation, the site will house S21 pro miners with an expected combined operating hashrate of approximately 1 exahashes per second (EH/s). The addition of these sites will bring the Company’s data center portfolio in Mississippi to 60.5 MW.

On September 11, 2024, the Company closed on its previously announced 45 MW site in Wyoming. The site is expected to contribute an additional 3 EH/s to the Company's hashrate upon completion. The site will feature immersion-cooled Bitcoin mining data centers which will support the latest generation S21 immersion XPs.

“Including today’s announcement, our operational capacity has soared over the last seven days totaling 211.5 MW of new capacity. That’s an increase of nearly 38 percent, which will not only support our target of 37 EH/s by the end of 2024, but also our target of 50 EH/s in 2025,” said Zach Bradford, CEO. “CleanSpark’s rapid growth underscores our ongoing commitment to deliver long-term shareholder value.”

About CleanSpark

CleanSpark (Nasdaq: CLSK) is America's Bitcoin Miner®. We own and operate multiple data centers that primarily run on low-carbon power. Our infrastructure responsibly supports Bitcoin, the world's most important digital commodity and an essential tool for financial independence and inclusion. We cultivate trust and transparency among our employees and the communities we operate in. Visit our website at www.cleanspark.com.

Forward-Looking Statements

This press release contains forward-looking statements within the meaning of the Private Securities Litigation Reform Act of 1995. In this press release, forward-looking statements include, but may not be limited to, statements regarding the Company's expectations, beliefs, plans, intentions, and strategies. In some cases, you can identify forward-looking statements by terms such as "may," "will," "should," "expects," "plans," "anticipates," "could," "intends," "targets," "projects," "contemplates," "believes," "estimates," "forecasts," "predicts," "potential" or "continue" or the negative of these terms or other similar expressions. The forward-looking statements are subject to a variety of known and unknown risks, uncertainties and other important factors that may cause our actual results, performance or achievements to be materially different from any future results, performance or achievements expressed or implied by the forward-looking statements, including, but not limited to: the timing of and closing of the 16.5 MW Mississippi acquisition; the timing of and completion of construction and energization of the Wyoming data

centers; anticipated additions and targets to CleanSpark's hashrate and the timing thereof; the risk that the electrical power available to our facilities does not increase as expected; the success of its digital currency mining activities; the volatile and unpredictable cycles in the emerging and evolving industries in which we operate; increasing difficulty rates for bitcoin mining; bitcoin halving; new or additional governmental regulation; the anticipated delivery dates of new miners; the ability to successfully deploy new miners; the dependency on utility rate structures and government incentive programs; dependency on third-party power providers for expansion efforts; the expectations of future revenue growth may not be realized; and other risks described in the Company's prior press releases and in its filings with the Securities and Exchange Commission (SEC), including under the heading "Risk Factors" in the Company's Annual Report on Form 10-K for the fiscal year ended September 30, 2023, and any subsequent filings with the SEC. Forward-looking statements contained herein are made only as to the date of this press release, and we assume no obligation to update or revise any forward-looking statements as a result of any new information, changed circumstances or future events or otherwise, except as required by applicable law.

Investor Relations Contact
Brittany Moore
702-989-7693
ir@cleanspark.com

Media Contact
Eleni Stylianou
702-989-7694
pr@cleanspark.com

Document And Entity Information	Sep. 16, 2024
Cover [Abstract]
Document Type	8-K
Amendment Flag	false
Document Period End Date	Sep. 16, 2024
Entity Registrant Name	CLEANSPARK, INC.
Entity Central Index Key	0000827876
Entity Emerging Growth Company	false
Entity File Number	001-39187
Entity Incorporation, State or Country Code	NV
Entity Tax Identification Number	87-0449945
Entity Address, Address Line One	10624 S. Eastern Ave.
Entity Address, Address Line Two	Suite A - 638
Entity Address, City or Town	Henderson
Entity Address, State or Province	NV
Entity Address, Postal Zip Code	89052
City Area Code	(702)
Local Phone Number	989-7692
Written Communications	false
Soliciting Material	false
Pre-commencement Tender Offer	false
Pre-commencement Issuer Tender Offer	false
Title of 12(b) Security	Common Stock, par value $0.001 per share
Trading Symbol	CLSK
Security Exchange Name	NASDAQ

CleanSpark (NASDAQ:CLSK)
Historical Stock Chart
Von Okt 2024 bis Nov 2024

CleanSpark (NASDAQ:CLSK)
Historical Stock Chart
Von Nov 2023 bis Nov 2024

Marktdaten

News

Werkzeuge

Märkte

Entdecken

Hot Features

Follow Feed

Optionen-Flow

Watchlist

CLSK CleanSpark Inc

News CleanSpark Inc

Kürzlich von Ihnen besucht

Unternehmen

Geschäft

Popular

App herunterladen

Trends

Toplisten

Marktdaten

News

Werkzeuge

Märkte

Entdecken

Hot Features

Follow Feed

Optionen-Flow

Watchlist

CLSK CleanSpark Inc

News CleanSpark Inc

Kürzlich von Ihnen besucht

Unternehmen

Geschäft

Popular

App herunterladen